Building Renovations It is specifically understood and agreed that Landlord has made no representation or warranty to Tenant and has no obligation and has made no promises to alter, remodel, improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Premises or the Building have been made by Landlord to Tenant except as specifically set forth herein or in the Work Letter. However, Tenant hereby acknowledges that Landlord is currently renovating or may during the Lease Term renovate, improve, alter, or modify (collectively, the “Renovations”) the Project, the Building and/or the Premises including without limitation the parking structure, common areas, systems and equipment, roof, and structural portions of the same, which Renovations may include, without limitation, (i) installing sprinklers in the Building common areas and tenant spaces, (ii) modifying the common areas and tenant spaces to comply with applicable laws and regulations, including regulations relating to the physically disabled, seismic conditions, and building safety and security, and (iii) installing new floor covering, lighting, and wall coverings in the Building common areas, and in connection with any Renovations, Landlord may, among other things, erect scaffolding or other necessary structures in the Building, limit or eliminate access to portions of the Project, including portions of the common areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Tenant hereby agrees that such Renovations and Landlord’s actions in connection with such Renovations shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of Rent. Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant’s business arising from the Renovations, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant’s personal property or improvements resulting from the Renovations or Landlord’s actions in connection with such Renovations, or for any inconvenience or annoyance occasioned by such Renovations or Landlord’s actions.
LESSOR'S ACCESS; SHOWING PREMISES; REPAIRS Lessor and Lessor's agents shall have the right to enter the Premises at any time, in the case of an emergency, and otherwise at reasonable times for the purpose of showing the same to prospective purchasers, lenders, or lessees, and making such alterations, repairs, improvements or additions to the Premises or to the Building, as Lessor may reasonably deem necessary. Lessor may at any time place on or about the Premises or Building any ordinary "For Sale" signs and Lessor may at any time during the last one hundred eighty (180) days of the term hereof place on or about the Premises any ordinary "For Lease" signs. All such activities of Lessor shall be without abatement of rent or liability to Lessee.
Renewal, Extension The renewal or extension of any Letter of Credit shall, for purposes hereof, be treated in all respects the same as the issuance of a new Letter of Credit hereunder.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Expansion Premises In addition to the Original Premises, commencing on the Expansion Premises Commencement Date (as defined below), Landlord leases to Tenant, and Tenant leases from Landlord, the Expansion Premises.
Additional Premises Landlord shall use commercially reasonable efforts to expand the Premises to include an additional fifteen thousand four hundred ten (15,410) square feet of Rentable Area located on the first (1st) floor, as shown on Exhibit A attached hereto (the “Additional Premises”) on July 1, 2012 (the “Additional Premises Delivery Date”). In the event Landlord determines the Additional Premises will be ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, within ten (10) business days prior to the Additional Premises Delivery Date, Landlord and Tenant shall enter into a written amendment to the Lease, which amendment shall provide, unless otherwise agreed in writing, (a) that the commencement date of the Additional Premises shall be the Additional Premises Delivery Date (the “Additional Premises Commencement Date”), (b) that, as of the Additional Premises Commencement Date, the Premises under the Lease shall be increased to include the Additional Premises for a total of sixty-one thousand four hundred forty-four (61,444) square feet of Rentable Area (together, the Premises and the Additional Premises shall be referred to hereinafter as the “Total Premises”), (c) the new Basic Annual Rent applicable to the Total Premises, which shall commence on the Additional Premises Commencement Date and shall be as further described in Section 4.2 of this Amendment, (d) Tenant’s new Pro Rata Share of Operating Expenses as of the Additional Premises Commencement Date, which Pro Rata Share shall equal one hundred percent (100%) of the Building and thirty-three and 51/100 percent (33.51%) of the Project and (e) that, in addition to the parking which Tenant is entitled to under the terms of the Lease with respect to the original Premises, Tenant, for so long as Tenant leases the Additional Premises, shall have a non-exclusive license to use the parking facilities serving the Building in common on an unreserved basis with other tenants of the Building and the Project at a ratio of 3.3 parking spaces per 1,000 rentable square feet of Additional Premises, which amounts to fifty-one (51) additional parking spaces, which number shall include three (3) additional Reserved Spaces. In the event the Additional Premises is not ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, then (x) this Amendment and the Lease shall not be void or voidable, (y) Landlord shall not be liable to Tenant for any loss or damage resulting therefrom and (z) the new Basic Annual Rent applicable to the Premises shall be as further described in Section 4.3 of this Amendment.
Extension Term (a) Tenant shall have the right to extend the Term for all of the Premises for one extension term of 5 years (the "Extension Term") which shall commence on the day following the expiration of the initial Term and end on the fifth anniversary of the Expiration Date, unless the Extension Term shall sooner terminate pursuant to any of the terms of this Lease or otherwise. The Extension Term shall commence only if (i) Tenant shall have notified Landlord in writing of Tenant's exercise of such extension right not later than nine (9) months prior to the Expiration Date, (ii) at the time of the exercise of such right and immediately prior to the Expiration Date, no event of Default shall have occurred and be continuing hereunder, and (iii) Tenant and/or Related Entities shall be in occupancy of at least 80 percent of the Premises at the time such notice is given. Time is of the essence with respect to the giving of the notice of Tenant's exercise of the extension option. The Extension Term shall be upon all of the agreements, terms, covenants and conditions hereof binding upon Tenant, except that (x) the Fixed Rent (as defined in Article 1) shall be determined as provided in Section 2.2(b), (y) Tenant shall have no further right to renew the Term and (z) Landlord shall have no obligation to provide any work or contribution to improve the Premises for Tenant's use. Upon the commencement of the Extension Term, (A) the Extension Term shall be added to and become part of the Term (but shall not be
Lease Extension Lessee may request Lessor to extend the original Scheduled Expiration Date of each Lease Agreement for an additional period of three (3) years by appropriately completing, executing and delivering to Agent a written request in the form of Exhibit G(2), together with an attachment thereto setting forth the terms upon which Lessee would propose for the requested extension (a "Lease Extension Request"). Lessee shall deliver each Lease Extension Request to Agent not more than twelve (12) months and not less than nine (9) months before the original Scheduled Expiration Date. Agent shall promptly deliver to Lessor and each Participant three (3) copies of each Lease Extension Request received by Agent. If Lessor or a Participant, in its sole and absolute discretion, consents to a Lease Extension Request, such Person shall evidence such consent by executing and returning two (2) copies of such Lease Extension Request to Agent not later than the last Business Day which is not less than seven (7) months prior to the original Scheduled Expiration Date for the applicable Lease Agreement. Any failure by Lessor or any Participant so to execute and return a Lease Extension Request shall be deemed a denial thereof. If Lessee shall deliver a Lease Extension Request to Lessor pursuant to the first sentence of this Subparagraph 2.09(b), then not later than the last Business Day which is not less than six (6) months prior to the original Scheduled Expiration Date for the applicable Lease Agreement, Agent shall notify Lessee, Lessor and the Participants in writing whether (i) Agent has received a copy of the Lease Extension Request executed by Lessor and each Participant, in which case the definition of "Scheduled Expiration Date" set forth in Subparagraph 2.02(a) of the applicable Lease Agreement shall be deemed extended to the date which is three (3) years after the original Scheduled Expiration Date (subject to the receipt by Agent of any amounts payable by Lessee in connection with such extension), or (ii) Agent has not received a copy of the Lease Extension Request executed by Lessor and each Participant, in which case such Lease Extension Request shall be deemed denied. Lessee acknowledges that neither Lessor nor any Participant has promised (either expressly or implicitly), or has any obligation or commitment, to extend or consent to the extension of the Scheduled Expiration Date for either Lease Agreement at any time.
Existing Premises Notwithstanding anything to the contrary in the Lease as hereby amended, Tenant shall continue to pay Base Rent for the Existing Premises in accordance with the terms of Article 3 of the Lease.
MAINTENANCE OF THE BUILDING /APARTMENT / PROJECT The Promoter shall be responsible to provide and maintain essential services in the Project till the taking over of the maintenance of the project by the Association upon the issuance of the completion certificate of the Project. The cost of such maintenance has been included in the Total Extras and Deposits as mentioned in clause 1.2.
