Procedure for execution of Conveyance Sample Clauses

Procedure for execution of Conveyance. Deed of the Unit and taking possession- The Promoter, within 60 days of obtaining the occupancy certificate from the competent authority, shall vide offer letter (“Offer Letter”)(i)invite Xxxxxxxx(s) (along-with details of outstanding dues and stamp duty, registration charges and other incidental charges to be paid by the Allottee(s) to the Promoter as per this Agreement before hand) to execute and register Conveyance Deed of the Unit; and (ii)offer the possession of the Unit. The Promoter shall, subject to receipt of Total Payable Amount in respect of the Apartment as per Payment Plan, delay interest, if any, and such other charges as mentioned under the Agreement from the Allottee(s), shall execute and register a Conveyance Deed and convey the title of the Unit together with proportionate indivisible share in common areas of Project and also handover possession of the Unit within three (3) months from the date of issuance of the occupancy certificate. The Promoter agrees and undertakes to indemnify the Allottee(s) in case of failure of fulfillment of any of the provisions, formalities, documentation on part of the Promoter which the Promoter is liable to comply/carry out as per the Applicable Laws provided such failure is not on account of reasons beyond the controls of Promoter and/or on account of any default/delay on the part of the Allottee(s). The Allottee(s), after taking possession (which shall be after the issuance of completion certificate for the Project) agree(s) to pay the maintenance charges along with applicable taxes as determined by the Promoteror Residents’ Association, as the case may be. The Promotershall handover the occupancy certificate of the Apartment to the Allottee(s) at the time of conveyance of the same.The Allottee(s) shall be solely responsible and liable for compliance of the provisions of Indian Stamp Act, 1899, Rajasthan Xxxxx Xxx, 0000 and Xxxxxxxxxxxx Xxx, 0000 including any actions taken or deficiencies/penalties imposed by the competent authority.The Promoter shall not be responsible for any damage caused to the Unit on account of delay on the part of the Allottee(s) in taking over possession and in such event the Allottee(s) shall have to take possession of the same on “as is where is basis”. The Promoter shall not be held responsible in any manner for any future mishaps like fire, earthquake, flood etc. OR any accident caused due to any of machineries installed like electrical equipment, and transformer, etc.
Sample 1See All (4)
AutoNDA by SimpleDocs
Procedure for execution of Conveyance. Deed of the Unit and taking possession- The Promoter, within 30 days of obtaining the occupancy certificate from the competent authority shall vide offer letter (“Offer Letter”)
Sample 1Sample 2

Related to Procedure for execution of Conveyance

  • NOTIFICATION OF PUBLIC EVENTS AND MEETINGS 2 A. CONTRACTOR shall notify ADMINISTRATOR of any public event or meeting funded in 3 whole or in part by the COUNTY, except for those events or meetings that are intended solely to serve 4 clients or occur in the normal course of business.

  • PROCEDURES FOR EVALUATION A. The evaluations of school year employees covered by this agreement shall be completed no later than May 30 of each school year for 9-month employees and by June 30 for 10/12-month employees. The evaluation shall be reviewed with the employee, with a copy given to the employee at the conclusion of the review. An employee may present written comments, which shall be attached to the written evaluation document. The evaluator and employee shall sign the evaluation document. The employee’s signature does not constitute approval or disapproval, but only that the evaluation has been reviewed with the employee.

  • Formal Grievance Procedure 1. In the event that a complaint cannot be resolved informally, the parties shall pursue the first step in the formal grievance procedure before making any application for arbitration, unless the College and the AAUP agree in writing to alter the procedure or waive one or more of the steps by proceeding directly to arbitration.

  • Board Procedure The Arbitrator may determine their own procedure in accordance with the Labour Relations Code and will give full opportunity to all parties to present evidence and make representations. They will hear and determine the difference or allegation and will make every effort to render a decision within 30 days of their first meeting.

  • Submission of Certified Payroll Transcripts for Public Works Contracts Only Contractors and Subcontractors on public works projects must submit monthly payroll transcripts to the Authorized User that has prepared or directs the preparation of the plans and specifications for a public works project, as set forth in the Bid Specifications. For Mini-Bid solicitations, the payroll records must be submitted to the entity preparing the agency Mini-Bid project specification. For “agency specific” Bids, the payroll records should be submitted to the entity issuing the purchase order. For all other OGS Centralized Contracts, such records should be submitted to the individual agency issuing the purchase order(s) for the work. Upon mutual agreement of the Contractor and the Authorized User, the form of submission may be submitted in a specified disk format acceptable to the Department of Labor provided: 1) the Contractor/Subcontractor retains the original records; and, (2) an original signed letter by a duly authorized individual of the Contractor or Subcontractor attesting to the truth and accuracy of the records accompanies the disk. This provision does not apply to Article 9 of the Labor Law building services contracts.

  • Award Procedures 8.1. The Award Procedures may be invoked by any Framework Public Body and Call-off Contracts may be entered into at any time during the period of the Framework Agreement.

  • AWARD PROCEDURE 1.1 If the Authority or any Other Contracting Body decides to source the Services through this Framework Agreement then it will award its Services Requirements in accordance with the procedure in this Framework Agreement Schedule 5 (Ordering Procedure) and the requirements of the Regulations and the Guidance.

  • Preparation and Organisation of Meetings The Chairperson shall convene ordinary meetings of the Project Committee at least once every 6 (six) months and shall also convene extraordinary meetings at any time upon written request of any Member.

  • Issues for Expedited Arbitration (a) All grievances except those relating to the following shall be resolved by expedited arbitration:

  • IN CASE OF ERRORS OR QUESTIONS ABOUT YOUR ELECTRONIC TRANSFERS In the event that you believe there has been an error with respect to any original check or image thereof transmitted to the Credit Union for deposit or a breach of this Agreement and Disclosure, you will immediately contact the Credit Union regarding such error or breach as set forth below. • By calling the Credit Union at: 000-000-0000; • By emailing the Credit Union at: xxxxxxxxxx@xxxxxxxxxxx.xxx; or • By writing a letter and sending it to P.O. Box 60890, Los Angeles, CA 00000-0000. Contact us as soon as you can if you think your statement or receipt is wrong or if you need more information about a transfer listed on the statement or receipt. We must hear from you no later than 60 days after we sent the FIRST statement on which the problem or error appeared. • Tell us your name and Account number. • Describe the error or the transfer you are unsure about, and explain as clearly as you can why you believe it is an error or why you need more information. • Tell us the dollar amount of the suspected error. If you tell us orally, we may require that you send us your complaint or question in writing within ten (10) business days. We will tell you the results of our investigation within ten (10)* business days after we hear from you and will correct any error promptly. If we need more time, however, we may take up to 45** days to investigate your complaint or question. If we decide to do this, we will provisionally credit your Account within ten (10)* business days for the amount you think is in error, so that you will have the use of the money during the time it takes us to complete our investigation. If we ask you to put your complaint or question in writing and we do not receive it within ten (10) business days, we may not credit your Account. If we decide that there was no error, we will send you a written explanation within three (3) business days after we finish our investigation. You may ask for copies of the documents that we used in our investigation. * If you assert an error within 30 days after you make the first deposit to your Account, we will have 20 business days instead of ten (10) business days. ** If you give notice of an error within 30 days after you make the first deposit to your Account, or notice of an error involving a transaction initiated outside the United States, its possessions and territories, we will have 90 days instead of 45 days to investigate. In accordance with Visa Operating Rules and Regulations, you will receive a provisional credit for Visa Check Card losses for unauthorized use within five (5) business days after you have notified us of the loss. This does not apply to ATM transactions using a PIN(s).

Time is Money Join Law Insider Premium to draft better contracts faster.