Indemnification and Defense 16.1 To the fullest extent permitted by California law, Developer shall indemnify, keep and hold harmless the District, the Architect(s) and Construction Manager(s), their respective consultants, separate contractors, board members, officers, representatives, agents, and employees, in both individual and official capacities (“Indemnitees”), against all suits, claims, injury, damages, losses, and expenses (“Claims”), including but not limited to attorney’s fees and costs, caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Contract by Developer or its Subcontractors, vendors and/or suppliers. However, Developer’s indemnification and hold harmless obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent the Claim(s) is/are caused wholly by the active negligence or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. This indemnification and hold harmless obligation of Developer shall not be construed to negate, abridge, or otherwise reduce any right or obligation of indemnity that would otherwise exist or arise as to any Indemnitee or other person described herein. This indemnification and hold harmless obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any law and/or provision of the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developers obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR.
Exculpation and Indemnification (a) No Protected Person shall be liable to the Company or any Manager or any other Member for any action taken or omitted to be taken by it or by other Person with respect to the Company, including any negligent act or failure to act, except in the case of a liability resulting from such Protected Person’s own actual fraud, gross negligence, willful misconduct, bad faith, breach of fiduciary duty, reckless disregard of duty or any intentional and material breach of this Agreement or conduct that is subject of a criminal proceeding (where such Protected Person has reasonable cause to believe that such conduct was unlawful). With the prior consent of the Board, any Protected Person may consult with legal counsel and accountants with respect to Company affairs (including interpretations of this Agreement) and shall be fully protected and justified in any action or inaction which is taken or omitted in good faith, in reliance upon and in accordance with the opinion or advice of such counsel or accountants. In determining whether a Protected Person acted with the requisite degree of care, such Protected Person shall be entitled to rely on written or oral reports, opinions, certificates and other statements of the directors, officers, employees, consultants, attorneys, accountants and professional advisors of the Company selected with reasonable care; provided that no such Protected Person may rely upon such statements if it believed that such statements were materially false.
Defense and Indemnification a. The Contractor hereby agrees to defend, indemnify, reimburse and hold harmless the City, its appointed and elected officials, agents and employees for, from and against all liabilities, claims, judgments, suits or demands for damages to persons or property arising out of, resulting from, or relating to the work performed under this Agreement (“Claims”), unless such Claims have been specifically determined by the trier of fact to be the sole negligence or willful misconduct of the City. This indemnity shall be interpreted in the broadest possible manner to indemnify the City for any acts or omissions of the Contractor or its subcontractors either passive or active, irrespective of fault, including the City’s concurrent negligence whether active or passive, except for the sole negligence or willful misconduct of the City.
Indemnification and Release Resident (and Guarantor, if Resident is under age 18) agrees to indemnify and hold harmless Provider, University, and their respective directors, board members, agents, and employees from and against all claims, actions, judgments, damages, liabilities, costs, demands, losses, and expenses (including, without limitation, reasonable attorneys’ fees and disbursements) resulting from or arising out of injury to the person or property of Resident or Resident’s guests while Resident resides in the Residence Facility, regardless of the cause (including, but not limited to, injury resulting from engagement, involvement, participation by Resident or any of Resident’s guests in any event sponsored by University or Provider) unless such injury is caused by the negligence or intentional misconduct of Provider, University, or their respective agents. Resident (and Guarantor, if Resident is under age 18) hereby release and forever discharge harmless Provider, University, and their respective directors, board members, agents, and employees from any and all demands, causes of action and/or judgments of whatsoever nature or character, past or future, known or unknown, whether in contract or tort, whether for personal injuries, property damage, payments, fees, expenses, or any other monies due or to become due, or damages of any kind or nature, and whether arising from common law or statute, arising out of, in any way, this Agreement and the use of the Residence Facility.
Indemnification and Save Harmless Provision The Association agrees to indemnify and hold the Board harmless against any liability which may arise by reason of any action taken by the Board in complying with the provisions of this Article.
Indemnification and Contribution (a) The Company agrees to indemnify and hold harmless each Underwriter, the directors, officers, employees and agents of each Underwriter, each person who controls any Underwriter within the meaning of either the Act or the Exchange Act and each affiliate of each Underwriter against any and all losses, claims, damages or liabilities, joint or several, to which they or any of them may become subject under the Act, the Exchange Act or other Federal or state statutory law or regulation, at common law or otherwise, insofar as such losses, claims, damages or liabilities (or actions in respect thereof) arise out of or are based upon any untrue statement or alleged untrue statement of a material fact contained in the Registration Statement for the registration of the Securities as originally filed or in any amendment thereof, or in any Preliminary Prospectus, the Statutory Prospectus, the Prospectus, any “roadshow” as defined in Section 433(h) of the Act or any Written Testing-the-Waters Communication or in any amendment thereof or supplement thereto, or arise out of or are based upon the omission or alleged omission to state therein a material fact required to be stated therein or necessary to make the statements therein not misleading, and agrees to reimburse each such indemnified party, as incurred, for any legal or other expenses reasonably incurred by them in connection with investigating or defending any such loss, claim, damage, liability, action, litigation, investigation or proceeding whatsoever (whether or not such indemnified party is a party thereto), whether threatened or commenced, and in connection with the enforcement of this provision with respect to any of the above as such expenses are incurred; provided, however, that the Company will not be liable in any such case to the extent that any such loss, claim, damage or liability arises out of or is based upon any such untrue statement or alleged untrue statement or omission or alleged omission made therein in reliance upon and in conformity with written information furnished to the Company by or on behalf of any Underwriter through the Representative specifically for inclusion therein, it being understood and agreed that the only such information furnished by any Underwriter consists of the information described in the last sentence of Section 8(b) hereof. This indemnity agreement will be in addition to any liability that the Company may otherwise have.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree (Yes) Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes Does Vendor agree? Yes, Vendor agrees (Yes) No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees (Yes)
Indemnification and Liability A. Neither the Contractor, OSC, nor the State shall be liable for any delay or failure in performance beyond its control resulting from acts of war, hostility or sabotage; act of God; electrical, internet or telecommunications outage that is not caused by the obligated party; or government restrictions, or other force majeure. The parties shall use reasonable efforts to eliminate or minimize the effect of such force majeure events upon performance of their respective duties under this Agreement. If such event continues for more than 90 days, either party may terminate all or any agreed upon portion of the Agreement immediately upon written notice. This section does not excuse either party’s obligation to take reasonable steps to follow its normal disaster recovery procedures, or OSC’s obligation to pay for Services provided by the Contractor which have been approved by OSC.
Indemnification and General Liability Section 10.4 Required Post-Expiration Coverage.
Indemnification/Hold Harmless The Exhibitor who signs this contract and each person associated therewith (i.e. employees, spouses, guests, survivors, heirs, executors and representatives) herein agrees to indemnify, defend, hold harmless, and to release and forever discharge from any and all known and unknown damages, injuries, death, loss, liabilities, claims, costs, penalties, demands, actions, causes of action, judgments, and liabilities of every kind and description (including court costs and attorney’s fees), occasioned by, resulting from, and/or related to conduct, actions, and/or omissions of anyone connected with this event, including: Xxxx Xxxx Xxxxxxxxxxx, Inc. d.b.a. Rod Shows, Fairplex, all other Exhibitors/Vendors at the event; and each of their respective owners, shareholders, officers, their directors, employees, agents, staff, volunteers, independent contractors, representatives and servants. Exhibitor covenants and agrees that in case Rod Shows shall be made party to any litigation commenced by or against exhibitor or relating to this agreement or to the booth space hereunder, then exhibitor shall and will pay all costs and expenses, including reasonable attorney fees and court costs, incurred by or imposed upon Rod Shows by virtue of any such litigation. SECURITY & PROPERTY DAMAGE Rod Shows will provide limited facility security and will exercise reasonable precaution for the protection of the exhibitors property. Rod Shows assumes no responsibility for loss or damage incurred during the rental period, or for any loss of items left onsite overnight. Neither Rod Shows or the vendor/exhibitor shall be responsible for any loss or damage to property of other party hereto including, but not limited to loss or damage occasioned by theft, fire, smoke, acts of God, public enemy, riot, civil commotion or other insurable hereto with respect to any loss or damage. It shall be the responsibility of Rod Shows and the Vendor/Exhibitor, respectively, to secure their own property insurance or otherwise protect themselves and their property against any such loss or damage. UNAVAILABILITY OF BOOTH SPACE
