Epidemic Failure Remedy If an Epidemic Failure occurs, all costs, including but not limited to, replacement Products, parts, upgrades, materials, labor, transportation and inventory replacement arising from an Epidemic Failure shall be borne by Supplier, regardless of whether DXC initiates a field stocking recall or customer-based recall or retrofit, including Products in distributor inventory and DXC’s installed base. Supplier, at its expense, will ensure that such Products, parts or upgrades have the highest shipping priority. DXC reserves the right to procure, upon terms it deems appropriate, similar products to substitute the affected Products, and Supplier shall promptly reimburse DXC for all costs, charges, prices and fees paid in purchasing the substitute products.
Epidemic Failure Warranty Supplier warrants all Products against Epidemic Failure for a period of three years after DXC’s Acceptance. Epidemic Failure means the occurrence of the same failure, defect, or non-conformity with an Order in 2% or more of Products within any three-month period.
Delay Damages If the Commercial Operation Date is not achieved by the date set forth therefor in Section 3.1(a) (as extended pursuant to Section 3.1(c)), Seller shall pay to Buyer damages for each month from and after such date until the Commercial Operation Date at the rate of $1.50 per kwh of Contract Maximum Amount up to a maximum of twelve (12) months of delay, pro rated for partial months (“Delay Damages”). Delay Damages shall be due under this Section 3.2(a) without regard to whether Buyer exercises its right to terminate this Agreement pursuant to Section 9.3; provided, however, that if Buyer exercises its right to terminate this Agreement under Section 9.3, Delay Damages shall be due and owing to the extent that such Delay Damages were due and owing at the date of such termination. If the Facility has not achieved the Commercial Operation by the date set forth therefor in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), for any reason, Seller shall have the right to terminate this Agreement at any time after that deadline date (as so extended) until either the Facility achieves the Commercial Operation Date or Buyer terminates this Agreement under Section 9.3 (regardless of whether or not Seller elected to continue to construct the Project). In the event Seller so terminates this Agreement, Seller shall be liable to Buyer on the date of such termination for (x) the entire amount of Delay Damages that would otherwise accrue (or have accrued) by such date plus (y) the undrawn amount of any Development Period Security provided to Buyer by Seller; provided, however, that if Seller terminates this Agreement on the deadline set forth for the Commercial Operation Date in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), Seller shall not be required to pay any Delay Damages hereunder but shall forfeit the Development Period Security. Subject to the foregoing sentence, neither Party shall have any liability to the other Party with respect to a termination of this Agreement by Seller under this Section 3.2(b). Each Party agrees and acknowledges that (i) the damages that Buyer would incur due to Seller’s delay in achieving the Commercial Operation Date would be difficult or impossible to predict with certainty, and (ii) it is impractical and difficult to assess actual damages in the circumstances stated, and therefore the Delay Damages and other damages as agreed to by the Parties and set forth herein are a fair and reasonable calculation of such damages. Notwithstanding the foregoing, this Article shall not limit the amount of damages payable to Buyer if this Agreement is terminated by Buyer as a result of Seller’s failure to achieve the Commercial Operation Date. Any such termination damages shall be determined in accordance with Article 9. By the tenth (10th) day following the end of the calendar month in which Delay Damages first become due and continuing by the tenth (10th) day of each calendar month during the period in which Delay Damages accrue (and the following months if applicable), Buyer shall deliver to Seller an invoice showing Buyer’s computation of such damages and any amount due Buyer in respect thereof for the preceding calendar month. No later than ten (10) days after receiving such an invoice, Seller shall pay to Buyer, by wire transfer of immediately available funds to an account specified in writing by Buyer or by any other means agreed to by the Parties in writing from time to time, the amount set forth as due in such invoice. If Seller fails to pay such amounts when due, Buyer may draw upon the Development Period Security for payment of such Delay Damages, and Buyer may exercise any other remedies available for Seller’s default hereunder.
Remedy Damages The Contractor shall promptly remedy damages and loss to property at the Site caused by the Contractor, by any Subcontractor, by anyone directly or indirectly employed by the Contractor or any such Subcontractor, or by anyone for whose acts the Contractor or any such Subcontractor may be liable. Should the Contractor cause damage to any Separate Contractor‘s work, the Contractor agrees, upon due notice, to settle with the Separate Contractor.
Failure to Cure If DSHS learns of a pattern or practice of the Business Associate that constitutes a violation of the Business Associate’s obligations under the terms of this Contract and reasonable steps by DSHS do not end the violation, DSHS shall terminate this Contract, if feasible. In addition, If Business Associate learns of a pattern or practice of its Subcontractors that constitutes a violation of the Business Associate’s obligations under the terms of their contract and reasonable steps by the Business Associate do not end the violation, Business Associate shall terminate the Subcontract, if feasible.
Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.
Payment in the Event Losses Fail to Reach Expected Level On the date that is 45 days following the last day (such day, the “True-Up Measurement Date”) of the Final Shared Loss Month, or upon the final disposition of all Shared Loss Assets under this Single Family Shared-Loss Agreement at any time after the termination of the Commercial Shared-Loss Agreement, the Assuming Institution shall pay to the Receiver fifty percent (50%) of the excess, if any, of (i) twenty percent (20%) of the Intrinsic Loss Estimate less (ii) the sum of (A) twenty-five percent (25%) of the asset premium (discount) plus (B) twenty-five percent (25%) of the Cumulative Shared-Loss Payments plus (C) the Cumulative Servicing Amount. The Assuming Institution shall deliver to the Receiver not later than 30 days following the True-Up Measurement Date, a schedule, signed by an officer of the Assuming Institution, setting forth in reasonable detail the calculation of the Cumulative Shared-Loss Payments and the Cumulative Servicing Amount.
Property Damages The User’s guests are required to respect all University property. • Guests may not remodel, alter, tamper with or move furniture, electrical or mechanical fixtures, or other University property. • The User agrees to refrain from the use of adhesives, nails, or items that may damage the premises. No decorations or temporary fixtures may be affixed to plants, trees, woodwork, buildings or any architectural feature with nails, tacks, staples, or any application that will cause irreversible damage to landscaping or structures. Duct tape and white masking tape are not permitted on any building, hardscape or lighting fixtures. Neither lights nor decorations may be placed on trees or plants. • Any outdoor signage must be reviewed and approved by University prior to installation. Stakes may not be placed deeper than 5 inches into the grass in order to protect sprinklers and other underground pipes. • Charges will be assessed on the Final Invoice for damages to buildings, furniture, lawns and/or equipment. The University will, to the best of its ability, try to document the names of guests when damages occur but cannot always obtain such information.
Force Majeure Failure Buyer shall have the right, but not the obligation, to terminate this Agreement after the occurrence of the following:
Breach of Contract Claims To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.
