Design and Construction Work Sample Clauses

Design and Construction Work. All work by Frontier, including but not limited to, space design and preparation, the rearrangement of existing facilities, design and construction of Partitioned Space enclosure, design and placement of required support structure or any other activity required to accommodate the installation of Carrier's facilities in the Frontier space(s) covered under this Agreement. Similar work required by Carrier after initial installation solely because of the existence of the Carrier's Facilities shall be referred to as "Additional Design and Construction," and shall be at Carrier's expense, subject to Carrier's pre-approval of the price of the work to be performed.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Design and Construction Work. All work by Frontier, including but not limited to, space design and preparation, the rearrangement of existing facilities, design and construction of Partitioned Space enclosure, design and placement of required support structure or any other activity required to accommodate the installation of CLC 's facilities in the Frontier space(s) covered under this Agreement. Similar work required by CLC after initial installation solely because of the existence of CLC 's Facilities shall be referred to as "Additional Design and Construction," and shall be at CLC 's expense, subject to CLC 's pre-approval of the price of the work to be performed.
Sample 1Sample 2Sample 3See All (5)
Design and Construction Work. All work by Frontier, including but not limited to, space design and preparation, the rearrangement of existing facilities, design and construction of Partitioned Space enclosure, design and placement of required support structure or any other activity required to accommodate the installation of INdigital's facilities in the Frontier space(s) covered under this Agreement. Similar work required by INdigital after initial installation solely because of the existence of INdigital's Facilities shall be referred to as "Additional Design and Construction," and shall be at INdigital's expense, subject to INdigital's pre-approval of the price of the work to be performed.
Sample 1
Design and Construction Work. All work by Frontier, including but not limited to, space design and preparation, the rearrangement of existing facilities, design and construction of Partitioned Space enclosure, design and placement of required support structure or any other activity required to accommodate the installation of CC's facilities in the Frontier space(s) covered under this Agreement. Similar work required by CC after initial installation solely because of the existence of CC's Facilities shall be referred to as "Additional Design and Construction," and shall be at CC's expense, subject to CC's pre- approval of the price of the work to be performed.
Sample 1

Related to Design and Construction Work

  • Design and Construction In complying with the requirements of the specification both with respect to arrangement and detail, design is to conform to the best current engineering practice. Each of the several parts of the material is to be of the maker’s standard design provided that this design is in general accordance with the specification. The essence of design should be simplicity and reliability in order to give long continuous service with high economy and low maintenance cost. Particular attention should be paid to internal and external access in order to facilitate inspection, cleaning and maintenance. The design dimensions and materials of all parts are to be such that they will not suffer damage as a result of stresses under the most severe conditions. Fully detailed specifications of the several parts of the material are to be submitted describing particularly the materials to be used. The materials used in the construction of the material are to be of the highest quality and selected particularly to meet the duties required of them. Mechanisms are to be constructed to avoid sticking due to rust or corrosion. Workmanship and general finish are to be of the highest class throughout. All similar parts of the material are to be interchangeable. All equipment is to operate without undue vibration and with the least possible amount of noise and is not to cause a nuisance. All equipment is to be designed to minimize the risk of fire and any damage, which may be caused in the event of fire. The equipment is also to be designed to prevent ingress of all vermin, accidental contact with live parts and to minimize the ingress of dust and dirt. The use of materials, which may be liable to attack by termites or other insects, is to be avoided.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure:

  • PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • New Construction If this contract is for a Property that is newly constructed and the new construction option is selected, coverage begins on day one (1) of month thirteen

  • Commencement and Completion of Construction The Company shall begin Construction Activities no later than January 1, 2014 (“Commencement Date”) and secure a final Certificate of Compliance by August 27, 2015 (hereinafter, “Completion Date”).

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • ADDITIONAL CONSTRUCTIONS The Promoter undertakes that it has no right to make additions or to put up additional structure(s) anywhere in the Project after the building plan has been approved by the competent authority(ies) except for as provided in the Act.

  • Review and Construction of Documents Each Party herein expressly represents and warrants to all other Parties hereto that (a) before executing this Agreement, said Party has fully informed itself of the terms, contents, conditions and effects of this Agreement; (b) said Party has relied solely and completely upon its own judgment in executing this Agreement; (c) said Party has had the opportunity to seek and has obtained the advice of its own legal, tax and business advisors before executing this Agreement; (d) said Party has acted voluntarily and of its own free will in executing this Agreement; and (e) this Agreement is the result of arm’s length negotiations conducted by and among the Parties and their respective counsel.

Time is Money Join Law Insider Premium to draft better contracts faster.