ADDITIONAL COMPENSATION FOR RERUNS Sample Clauses

ADDITIONAL COMPENSATION FOR RERUNS. A. Rerun fees shall be payable with respect to voice actor’s services in each film or segment thereof, as provided in the 2014 SAG-AFTRA Television Agreement, except that the network prime time rerun ceilings in Section 18(b)(1)b) of the 2011 Television Agreement shall apply to animated television motion pictures for which principal recording commences on or after July 1, 2014 but before October 1, 2014. For the purpose of computing “total actual compensationin connection with the payment of prime time network reruns, actual compensation for additional voices shall be included. For the purpose of determining the “total applicable minimum salary,” the total minimum salary paid to the voice actor for each film or segment, including any additional compensation paid for performing additional voices shall be deemed the voice actor’s total applicable minimum salary.
AutoNDA by SimpleDocs
ADDITIONAL COMPENSATION FOR RERUNS. 1. Network Prime Time Dramatic
ADDITIONAL COMPENSATION FOR RERUNS. SEGMENT RE-USE AND FOREIGN USE PAYMENTS

Related to ADDITIONAL COMPENSATION FOR RERUNS

  • Additional Compensation Notwithstanding anything in this Memorandum of Understanding to the contrary when in the judgment of the Board, it becomes necessary or desirable to utilize the services of County employees in capacities other than those for which they are regularly employed, the Board may authorize and, if appropriate, fix an additional rate of compensation for such employees.

  • Compensation for Overtime 9.5.1 All overtime hours, except those overtime hours exceeding twelve (12) hours in one day, shall be compensated at a rate of pay equal to time and one-half the regular rate of pay of the employee. Those overtime hours exceeding twelve (12) in one day shall be compensated at a rate of pay equal to two times the regular pay of the employee.

  • Compensation for Delay The time allowed for carrying out the work, as entered in the tender form, shall be strictly observed by the contractor and shall be deemed to be the essence of the contract and shall be reckoned from the fifteenth day after the date on which the order to commence the work is issued to the contractor, for a work where completion is up to 6 months For works, for which the completion period is beyond six months: - The period will be reckoned from the thirtieth day after the date on which the order to commence the work is issued to contractor .The work shall throughout the stipulated period of contract be proceeded with all due diligence, keeping in view that time is the essence of the contract. The contractor shall be bound in all cases, in which the time allowed for any work exceeds one month, to complete 1/8th of the whole work before 1/4th of the whole time allowed under the contract has elapsed, 3/8th of the work before 1/2 of such time has elapsed and 3/4th of the work before 3/4th of such time has elapsed. In the event of the contractor failing to comply with the above conditions, the Commissionor/CMO shall levy on the contractor, as compensation an amount equal to: 0.5% (zero point five percent) of the value of work (contract sum) for each week of delay, provided that the total amount of compensation under this provision of the clause shall be limited to 6% (six percent) of the value of work. (Contract sum) Provided further that if the contractor fails to achieve 30% (thirty percent) progress in half (1/2) of original or validly extended period of time (reference clause 5 below) the contract shall stand terminated after due notice to the contractor and his contract finallised, with xxxxxxx money and or security deposit forfeited and levy of further compensation at the rate of 10% of the balance amount of contract left incomplete, either from the bill, and or from available security/performance guarantee or shall be recovered as "Arrears of land revenue". The decision of the Competent Authority in the matter of grant of extension of time only (reference clause 5 below) shall be final, binding and conclusive. But he has no right to change either the rate of compensation or reduce and or condone the period of delay- once such an order is passed by him (on each extension application of the contractor). It shall not be open for a revision. Where the Commissioner/CMO or Competent Authority or Commissioner/CMO as the case may decides that the contractor is liable to pay compensation for not giving proportionate progress under this clause and the compensation is recommended during the intermediate period, such compensation shall be kept in deposit and shall be refunded if the contractor subsequently makes up the progress for the lost time, within the period of contract including extension granted, if any. failing which the compensation amount shall be forfeited in favour of the Nagar Xxxxx/Nagar Palika Parishad/Nagar Panchayat Clause 3 -:Action when the work is left incomplete abandoned or delayed beyond the time limit permitted by the Commissioner/CMO or Competent Authority: -

  • Supplemental Compensation Pursuant to Section 7 of the Agreement, Supplemental Compensation will be paid as follows:

  • Compensation for Additional Services Additional Services shall be compensated as set forth on Exhibit A for the stipulated payment amounts set forth therein. Other Additional Services not set forth on Exhibit A that are required or requested by the Owner shall be compensated as agreed, using the methodology set forth on Exhibit A, prior to the Design Professional undertaking such Additional Services; provided, however, that if such compensation cannot be agreed, the Additional Services shall be performed at the hourly rates set forth and listed in Exhibit B, plus reimbursable expenses pursuant to Article 4.1.3 below, with a limitation as to maximum amount specified.

  • Compensation for Losses Upon demand of any Lender (with a copy to the Administrative Agent) from time to time, the Borrower shall promptly compensate such Lender for and hold such Lender harmless from any loss, cost or expense incurred by it as a result of:

  • Final Compensation Final Compensation for an employee, who is employed by the State for the first time and becomes a member of CalPERS prior to January 15, 2011, is based on the highest average monthly pay rate during twelve (12) consecutive months of employment. Final Compensation for an employee, who is employed by the State for the first time and becomes a member of CalPERS on or after January 15, 2011, is based on the highest average monthly pay rate during thirty-six (36) consecutive months of employment.

  • Eligibility for Overtime Compensation (a) Overtime compensation rates for all hours worked in excess of the workday and workweek identified below shall be as follows:

  • Supplementation of Compensation Award ‌ If an employee is prevented from performing the employee's regular work with the City on account of an occupational accident that is recognized by the Workers' Compensation Board as compensable within the meaning of the Workers' Compensation Act, the City will supplement the award made by the Workers' Compensation Board for loss of wages to the employee by such an amount that the award of the Workers' Compensation Board for loss of wages (excluding non- economic loss payment), together with the supplementation by the City, will equal 100% of the employee's regular net wage (gross pay less statutory deductions, union dues and required benefit plan contributions). The said supplementation shall not be payable to any employee entitled to compensation after pension age if such an employee is entitled to an unreduced pension as provided under the Local Authorities Pension Plan or after the full age of 65 years if such an employee is not entitled to a pension. Subject to the foregoing limitation, the procedure to be followed in operating this policy shall be as follows:

  • Compensation for Reimbursable Expenses 11.8.1 Reimbursable Expenses are in addition to compensation for Basic, Supplemental, and Additional Services and include expenses incurred by the Architect and the Architect’s consultants directly related to the Project, as follows:

Time is Money Join Law Insider Premium to draft better contracts faster.