WITHHELD AIRCRAFT Sample Clauses

WITHHELD AIRCRAFT. Contractor and ABX agree and recognize that the twelve (12) additional aircraft (“Withheld Aircraft”) are currently assets of Delta, which has recently filed for Chapter Eleven protection under U.S. Bankruptcy Code. For the sale of the Withheld Aircraft to be consummated and for ABX to properly take ownership and delivery of the Withheld Aircraft, the court reviewing Delta’s bankruptcy petition must approve and allow the sale of all the Withheld Aircraft to ABX. If the reviewing court approves the sale of all the Withheld Aircraft to ABX and ABX takes delivery from Delta of all the Withheld Aircraft, then the Withheld Aircraft will then become “Additional Aircraft” hereunder and will be subject to the terms and conditions below. If the court reviewing Delta’s Chapter Eleven petition rejects or disallows all or part of the purchase by, or delivery to, ABX of the Withheld Aircraft or ABX is otherwise unable to take delivery of all or part of the Withheld Aircraft from Delta, then such Withheld Aircraft will not be considered Additional Aircraft and neither party hereunder will owe the other party any damages, direct or otherwise, and the obligations and rights of Contractor and ABX hereunder will be null and void.
Sample 1
AutoNDA by SimpleDocs

Related to WITHHELD AIRCRAFT

  • Return of Aircraft 64 23.1 Date of Return................................................64 23.2

  • Aircraft This peril includes self-propelled missiles and spacecraft.

  • Lease of Aircraft Lessor agrees to lease the Aircraft to Lessee pursuant to the provisions of FAR Section 91.501(b)(6) and Section 91.501(c)(1) and this Agreement, and to provide a fully-qualified and credentialed flight crew for all flights to be conducted hereunder during the Term (as defined in Section 13) hereof. The parties acknowledge and agree that this Agreement did not result in any way from any direct or indirect advertising, holding out or soliciting on the part of Lessor or any person purportedly acting on behalf of Lessor. Lessor and Lessee intend that the lease of the Aircraft effected by this Agreement shall be treated as a “wet lease” pursuant to which Lessor provides transportation services to Lessee in accordance with FAR Section 91.501(b)(6) and Section 91.501(c)(1).

  • Aircraft Basic Price The Aircraft Basic Price is listed in Table 1 and is subject to escalation in accordance with the terms of this Purchase Agreement.

  • Condition of Aircraft Upon any Return Occasion, Lessee shall return such Aircraft to Lessor in such condition that the Aircraft shall also comply with each and every condition and requirement set forth elsewhere in this Lease, including Exhibit E hereto.

  • DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.

  • Delivery Location All Goods shall be delivered to the address specified in this Order (the "Delivery Location") during Buyer's normal business hours or as otherwise instructed by Buyer.

  • Delivery Point (a) All Energy shall be Delivered hereunder by Seller to Buyer at the Delivery Point. Seller shall be responsible for the costs of delivering its Energy to the Delivery Point consistent with all standards and requirements set forth by the FERC, ISO-NE, the Interconnecting Utility and any other applicable Governmental Entity and any applicable tariff.

  • Equipment Installation In order to meet its obligations under this Agreement, a Party that owns, rents, or leases equipment (the equipment owner) may require installation of such equipment on property owned by another Party (the property owner), provided that the property is being used for an electric utility purpose and that the property owner shall not be required to do so if it would thereby be prevented from performing its own obligations or exercising its rights under this Agreement.

  • Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 45 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, and if so terminated by Tenant: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenant Delays” and “Substantially Completed” shall have the meanings set forth for such terms in the Work Letter. If Tenant does not elect to void this Lease within 10 business days of the lapse of such 45 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Notwithstanding anything to the contrary contained herein, if Tenant does not terminate this Lease pursuant to the immediately preceding sentence, Base Rent shall be abated 1 day for each day after such 45 day period (as extended by Force Majeure delays and Tenant Delays) that the Premises are not Delivered to Tenant.

Time is Money Join Law Insider Premium to draft better contracts faster.