under this Lease definition

under this Lease. Building Standard Consumption" shall mean the consumption necessary, in Lessor's reasonable judgment, for use and comfortable occupancy of the Demised Premises when occupied by the density of people for which the building standard system was designed with occupants using Standard Office Equipment. "Standard Office Equipment" shall mean all office equipment normally found in an office facility but shall not include computer and communication systems (other than personal computers and fax machines in numbers typical of standard office use), telephone switches and conference or training rooms (or items similar thereto) which require Additional Electric Equipment, as hereinafter defined in Paragraph 22(e) below, or additional air conditioning service or systems. In determining Lessee's pro rata share for the foregoing services for any period, the cost for the foregoing services shall be deemed for such period to be an amount equal to the like expenses which Lessor reasonably determines would normally be incurred had the Building been fully occupied throughout such period.
Sample 1

Examples of under this Lease in a sentence

  • Time is of the essence with respect to the performance of all obligations to be performed or observed by the Parties under this Lease.

  • The minimum limits of policies of insurance required of Tenant under this Lease shall in no event limit the liability of Tenant under this Lease.

  • The obligation of Tenant to pay Base Rent and other sums to Landlord and the obligations of Landlord under this Lease are independent obligations.

  • If there is more than one Tenant, the obligations imposed upon Tenant under this Lease shall be joint and several.

  • Upon any assignment, the assignee shall assume in writing all obligations and covenants of Tenant thereafter to be performed or observed under this Lease.

  • No collection or acceptance of rent by Landlord from any Transferee shall be deemed a waiver of any provision of this Article 14 or the approval of any Transferee or a release of Tenant from any obligation under this Lease, whether theretofore or thereafter accruing.

  • No termination, cancellation or release agreement entered into by Lessor and Lessee shall release Lessee from its obligations under this Lease with respect to Hazardous Substances, unless specifically so agreed by Lessor in writing at the time of such agreement.

  • All obligations of Landlord under this Lease will be binding upon Landlord only during the period of its ownership of the Premises and not thereafter.

  • Except as provided in Paragraph 15, upon such transfer or assignment and delivery of the Security Deposit, as aforesaid, the prior Lessor shall be relieved of all liability with respect to the obligations and/or covenants under this Lease thereafter to be performed by the Lessor.

  • The Security Deposit shall be held by Landlord as security for the performance of Tenant’s obligations under this Lease.

Related to under this Lease

  • this Lease means the relevant portion of Articles 1 through 29 of this Office Lease to which this Tenant Work Letter is attached as EXHIBIT B and of which this Tenant Work Letter forms a part, and all references in this Tenant Work Letter to sections of "this Tenant Work Letter" shall mean the relevant portion of Sections 1 through 7 of this Tenant Work Letter.

  • this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.

  • Lease Term means the term of this Lease which shall commence on the Commencement Date and continue for the period specified in Section J of the Summary.

  • Master Lease means any master lease now or hereafter entered into, in which the Healthcare Facility is aggregated with other HUD-insured healthcare facilities and leased to a Master Tenant and any amendments or joinders thereto.

  • Tenant Delays A "Tenant Delay" shall mean any delay in Substantial Completion of the Building as a result of any of the following: (i) Tenant's failure to complete or approve the Tenant Improvement Plans by the dates set forth in Section 5.B, (ii) Tenant's failure to approve the bids for construction by the dates set forth in Section 5.C, (iii) changes to either the Shell Plans and Specifications or the Tenant Improvement Plans requested by Tenant which delay the progress of the work, (iv) Tenant's request for materials, components or finishes which are not available in a commercially reasonable time given the target Commencement Date, (v) Tenant's failure to make a progress payment for Tenant Improvement costs as provided in Section 5.F, (vi) Tenant's request for more than one (1) rebidding of the cost of all or a portion of the work, and (vii) any errors or omissions in the Tenant Improvement Plans provided by Tenant's architect. In the event Landlord believes Tenant is causing a Tenant Delay, Landlord shall notify Tenant in writing, state the action or inaction that it believes is causing the Tenant Delay, and state the date from which a Tenant Delay is being calculated. Claim of Tenant Delay shall be made within five (5) days after Landlord's discovery of the occurrence of the event giving rise to such claim. Tenant shall have the right to expedite work, at its sole cost, to minimize the effect of any Tenant Delays, to the extent it is practicable to do so. However, no Tenant Delay shall advance the Commencement Date to a date before the estimated Commencement Date of October 1, 2001. Notwithstanding anything to the contrary set forth in this Lease and regardless of the actual date the Premises are Substantially Complete (but subject to the limitation in the preceding sentence), the Commencement Date shall be deemed to be the date the Commencement Date would have occurred if no Tenant Delay had occurred as reasonably determined by Landlord. In addition, if a Tenant Delay results in an increase in the cost of the labor or materials, Tenant shall pay the cost of such increases.

  • Tenant Delay Any event or occurrence that delays the completion of the Landlord Work which is caused by or is described as follows:

  • Premises Total Destruction means damage or destruction to the Premises, other than Lessee Owned Alterations and Utility Installations and Trade Fixtures, which cannot reasonably be repaired in six (6) months or less from the date of the damage or destruction. Lessor shall notify Lessee in writing within thirty (30) days from the date of the damage or destruction as to whether or not the damage is Partial or Total.

  • Subleased Premises means such portions of the Leased Premises being particularly identified on Schedule B, which the parties agree, for the purposes of this Sublease and any square footage calculations pursuant hereto, is approximately 42,244 square feet of office (21,068 square feet on the third floor and 21,176 square feet on the seventh floor) and approximately 9.4312% of common space (building rentable area is 447,917 square feet).

  • Premises Building Total Destruction means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is fifty percent (50%) or more of the then Replacement Cost of the Building.

  • Leased Premises means the Leased Premises as defined in Paragraph 1.

  • Rent as used in this Section 21 shall be deemed to be and to mean all sums of every nature required to be paid by Tenant pursuant to the terms of this Lease, whether to Landlord or to others. As used in Sections 21(c)(ii)(A) and (B), above, the “worth at the time of award” shall be computed by allowing interest at the Default Rate. As used in Section 21(c)(ii)(C) above, the “worth at the time of award” shall be computed by discounting such amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus 1%.

  • Leased Property shall have the meaning given such term in Section 2.1.

  • Master Lease Agreement has the meaning set forth in Section 7.2(c)(xiv).

  • Lease Agreement means the bargain, with respect to the lease, of the lessor and the lessee in fact as found in their language or by implication from other circumstances including course of dealing or usage of trade or course of performance as provided in this article. Unless the context clearly indicates otherwise, the term includes a sublease agreement.

  • Sublease Agreement shall have the meaning specified in Section 8.2(b).

  • Ready for Occupancy means the date upon which (i) the Leased Premises are available for Tenant's occupancy in a broom clean condition and (ii) the improvements, if any, to be made to the Leased Premises by Landlord as a condition to Tenant's obligation to accept possession of the Leased Premises have been substantially completed and the appropriate governmental building department (i.e., the City building department, if the Property is located within a City, or otherwise the County building department) shall have approved the construction of such improvements as substantially complete or is willing to so approve the construction of the improvements as substantially complete subject only to compliance with specified conditions which are the responsibility of Tenant to satisfy or is willing to allow Tenant to occupy subject to its receiving assurances that specified work will be completed.

  • the Tenant means the party(ies) named on the tenancy agreement as the tenant of The Property.

  • domestic premises means any premises used wholly or partly as a dwelling or intended for such use;

  • Premises Building Partial Damage means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is less than fifty percent (50%) of the then Replacement Cost of the building.

  • Tenant’s Property means Removable Installations and, other than Installations, any personal property or equipment of Tenant that may be removed without material damage to the Premises, and (z) “Installations” means all property of any kind paid for by Landlord, all Alterations, all fixtures, and all partitions, hardware, built-in machinery, built-in casework and cabinets and other similar additions, equipment, property and improvements built into the Premises so as to become an integral part of the Premises, including, without limitation, fume hoods which penetrate the roof or plenum area, built-in cold rooms, built-in warm rooms, walk-in cold rooms, walk-in warm rooms, deionized water systems, glass washing equipment, autoclaves, chillers, built-in plumbing, electrical and mechanical equipment and systems, and any power generator and transfer switch.

  • Released Property shall have the meaning set forth in Section 2.10 hereof.

  • Ground Lease means a lease creating a leasehold estate in real property where the fee owner as the ground lessor conveys for a term or terms of years its entire interest in the land and buildings and other improvements, if any, comprising the premises demised under such lease to the ground lessee (who may, in certain circumstances, own the building and improvements on the land), subject to the reversionary interest of the ground lessor as fee owner. With respect to any Mortgage Loan where the Mortgage Loan is secured by a Ground Leasehold estate in whole or in part, and the related Mortgage does not also encumber the related lessor’s fee interest in such Mortgaged Property, based upon the terms of the Ground Lease and any estoppel or other agreement received from the ground lessor in favor of Mortgage Loan Seller, its successors and assigns (collectively, the “Ground Lease and Related Documents”), Mortgage Loan Seller represents and warrants that: