PV Power Plant Substantial Completion Guaranteed Date definition

PV Power Plant Substantial Completion Guaranteed Date means ***, as such date may be adjusted or extended pursuant to the terms hereof.
Sample 1

Examples of PV Power Plant Substantial Completion Guaranteed Date in a sentence

  • The CPM Schedule shall represent Contractor's best judgment as to how it shall complete the Work in compliance with the Schedule Milestones including the Phase Substantial Completion Guaranteed Dates, the PV Power Plant Substantial Completion Guaranteed Date, and the Final Completion Guaranteed Date.

  • As part of the Monthly Progress Report, Contractor shall update the CPM Schedule monthly to reflect the actual progress to date (“Monthly Updated CPM Schedule”); provided, however, Contractor may not modify the Phase Substantial Completion Guaranteed Dates or the PV Power Plant Substantial Completion Guaranteed Date without a Change In Work Form being executed pursuant to this Agreement, nor shall Contractor change any dates that relate to Owner's obligations without obtaining Owner's written consent.

  • The Initial Shareholder and each of the First Fleet Shareholders hereby acknowledge that the Underwriters are third party beneficiaries of this Agreement and this Agreement may not be modified or changed without the prior written consent of Xxxxxxx.

Related to PV Power Plant Substantial Completion Guaranteed Date

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Subproject means a specific activity carried out under Part 1 of the Project, financed or proposed to be financed through a Subproject Loan (as hereinafter defined).

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Completion Guaranty means the Completion Guaranty of even date herewith executed by Guarantor in favor of Lender in connection with the Capital Improvement Work and the Loan, as amended from time to time.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Substantial compliance means a level of compliance with these rules where any deficiencies pose no greater risk to resident health or safety than the potential for causing minor harm.

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • Certificate of Substantial Completion means the certificate executed by the A/E, ODR and Contractor that documents to the best of A/E’s and ODR’s knowledge and understanding, Contractor’s sufficient completion of the work in accordance with the Contract, so as to be operational and fit for the use intended.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.

  • Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Construction project means the same as that term is defined in Section 38-1a-102.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.