PV Power Plant definition

PV Power Plant means the photovoltaic energy generating facility to be designed, engineered, procured, constructed, tested and commissioned under this Agreement in Phases as provided herein and as described in the Plant Specifications.
Sample 1

Examples of PV Power Plant in a sentence

  • The CPM Schedule shall represent Contractor's best judgment as to how it shall complete the Work in compliance with the Schedule Milestones including the Phase Substantial Completion Guaranteed Dates, the PV Power Plant Substantial Completion Guaranteed Date, and the Final Completion Guaranteed Date.

  • The control and monitoring workstation shall be equipped for real-time detailed monitoring of PV Power Plant performance.

  • The Initial Shareholder and each of the First Fleet Shareholders hereby acknowledge that the Underwriters are third party beneficiaries of this Agreement and this Agreement may not be modified or changed without the prior written consent of Xxxxxxx.

  • Completion for prior Phase(s) or PV Power Plant Substantial Completion, as applicable) minus (as the sole compensation to Owner for its lost revenue during the Cure Period) an amount equal to the following: ***.

  • Notwithstanding the foregoing, Contractor shall be entitled to reasonable access to the applicable Phase and/or the PV Power Plant between sunset and sunrise.

  • The License granted to Owner pursuant to this Section 32.2 is granted only to the extent of Contract Intellectual Property that is included in the PV Power Plant, the Project, the Work or the Contractor Deliverables, including the Required Manuals.

  • Notwithstanding anything to the contrary in this Section 25, Contractor shall have the right to utilize general information about the PV Power Plant, including photographs, in its promotional materials and public statements.

  • Owner's review of the CPM Schedule shall not relieve Contractor of any obligations for the performance of the Work, change the Phase Substantial Completion Guaranteed Dates, the PV Power Plant Substantial Completion Guaranteed Dates, or the Final Completion Guaranteed Dates.

  • If, based on the results of the most recent Performance Acceptance Test that has been Successfully Run with respect to a Phase prior to its Phase Substantial Completion, such Phase (or in the case of the last Phase, the PV Power Plant) has *** CONFIDENTIAL MATERIAL REDACTED AND SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION.

  • Contractor shall design, engineer and construct the PV Power Plant so that it meets the requirements of the Statement of Work and is capable of operation in compliance with this Agreement, all Applicable Laws, Applicable Permits and Industry Standards in effect as of the Effective Date.

Related to PV Power Plant

  • Power Plant means a facility for the generation of

  • Power Project or “Project” shall mean the Solar power generation facility of Contracted Capacity of ………..[Insert capacity] MW, located at [Insert name of the place] in …. [Insert name of the District and State] having a separate control system, metering and separate points of injection into the grid at Delivery/Interconnection/Metering point at ISTS substation or in case of sharing of transmission lines, by separate injection at pooling point. This includes all units and auxiliaries such as water supply, treatment or storage facilities; bay/s for transmission system in the switchyard, dedicated transmission line up to the Delivery Point and all the other assets, buildings/structures, equipment, plant and machinery, facilities and related assets required for the efficient and economic operation of the power generation facility; whether completed or at any stage of development and construction or intended to be developed and constructed for the purpose of supply of power as per this Agreement;

  • generating plant means the generating facility described in Schedule 1 as amended from time to time;

  • Cogeneration facility means a power plant in which the heat or steam is also used for industrial or commercial heating or cooling purposes and that meets Federal Energy Regulatory Commission standards for qualifying facilities under the Public Utility Regulatory Policies Act of 1978 (16

  • Plant means the machinery and apparatus intended to form or forming part of the Works.

  • Geothermal energy means energy contained in heat that continuously flows outward from the earth that is used as the sole source of energy to produce electricity.

  • Plant Site (Works, Factory) means the local integration of one or more plants, with any intermediate administrative levels, which are under one operational control, and includes common infrastructure, such as:

  • Station Power means energy used for operating the electric equipment on the site of a generation facility located in the PJM Region or for the heating, lighting, air-conditioning and office equipment needs of buildings on the site of such a generation facility that are used in the operation, maintenance, or repair of the facility. Station Power does not include any energy (i) used to power synchronous condensers; (ii) used for pumping at a pumped storage facility; (iii) used in association with restoration or black start service; or (iv) that is Direct Charging Energy. Surplus Interconnection Customer:

  • cogeneration means the simultaneous generation in one process of thermal energy and electrical or mechanical energy;

  • Cogeneration unit means a unit that is able to operate in cogeneration mode;

  • Project Company means Company incorporated by the bidder as per Indian Laws in accordance with Clause no 3.5.

  • Interconnection Facilities means the Transmission Owner Interconnection Facilities and the Customer Interconnection Facilities.

  • Gasification means the substoichiometric oxidation or steam reformation of a substance to produce a gaseous mixture containing two or more of the following: (i) oxides of carbon; (ii) methane; and (iii) hydrogen;

  • Reactive Power means the wattless component of the product of voltage and current, which the Facility shall provide to or absorb from the Grid System within the Technical Limits and which is measured in MVAR;

  • Substation means the apparatus that connects the electrical collection system of the WECS(s) and increases the voltage for connection with the utility's transmission lines.

  • Solar PV Project means the solar Photo Voltaic Power project that uses sunlight for direct conversion into electricity through Photo Voltaic technology.

  • Active Power has the meaning given to it in the Grid Code;

  • Geothermal fluid means water in any form at temperatures greater than 120