Excusable Failure definition

Excusable Failure means an incidence of failure on the part of the Service Provider to perform any element or part of the Services in accordance with the Contract where the failure is, in the sole and reasonable opinion of the Purchaser wholly or mainly attributable to some event or series of related events which are outside of the reasonable control of the Service Provider and/or are wholly exceptional or catastrophic which would affect all providers of services similar to the Services in the geographical area in which the failure arose. The limit of time of the effect of such failure is at the sole and reasonable discretion of the Purchaser;
Sample 1Sample 2Sample 3
Excusable Failure means any failure due to a force majeure or any failure due to reasons beyond the control of PA.
Sample 1
Excusable Failure means an incidence of failure on the part of the Service Provider to perform any element or part of the Services in accordance with the Contract where the failure is, in the sole and reasonable opinion of the Purchaser wholly or mainly attributable to some event or series of related events which are outside of the reasonable control of the Service Provider and/or are wholly exceptional or catastrophic which would affect all providers of services similar to the Services in the geographical area in which the failure arose, or accepted by the Purchaser as a situation covered by agreed mitigation. The limit of time of the effect of such failure is at the sole and reasonable discretion of the Purchaser;
Sample 1

Examples of Excusable Failure in a sentence

  • The Contractor will not have the right to any additional payments from the State as a result of any Excusable Failure occurrence or to payments for Services not rendered/Deliverables not provided as a result of the Excusable Failure condition.

  • SLAs will not be calculated for individual Incidents where any event of Excusable Failure has been determined; Incident means any interruption in Services.

  • Defaults or delays in performance by Contractor which are caused by acts or omissions of its Subcontractors will not relieve Contractor of its obligations under the Contract except to the extent that a Subcontractor is itself subject to an Excusable Failure condition described above and Contractor cannot reasonably circumvent the effect of the Subcontractor’s default or delay in performance through the use of alternate sources, workaround plans or other means.

  • This warranty does not apply to defects arising from acts of Excusable Failure.

  • Defaults or delays in performance by Contractor which are caused by acts or omissions of its Subcontractors will not relieve Contractor of its obligations under this Contract except to the extent that a Subcontractor is itself subject to an Excusable Failure condition described above and Contractor cannot reasonably circumvent the effect of the Subcontractor’s default or delay in performance through the use of alternate sources, workaround plans or other means.

  • The Contractor will not be relieved of a default or delay caused by acts or omissions of its Subcontractors except to the extent that a Subcontractor experiences an Excusable Failure and the Contractor cannot reasonably circumvent the effect of the Subcontractor's default or delay in performance through the use of alternate sources, workaround plans, or other means, including disaster recovery plans.

  • The Contractor will not be relieved of a default or delay caused by acts or omissions of its Subcontractors except to the extent that a Subcontractor experiences an Excusable Failure and the Contractor cannot reasonably circumvent the effect of the Subcontractor's default or delay in performance through the use of the contractor’s sources, workaround plans, or other means, including disaster recovery plans.

  • The Contractor will not have the right to any additional payments from Huron Valley Schools as a result of any Excusable Failure or to payments for deliverable(s) not provided as a result of the Excusable Failure.

  • The Contractor will not have the right to any additional payments from the State as a result of any Excusable Failure or to payments for Deliverable(s) not provided as a result of the Excusable Failure.

  • The Contractor will not have the right to any additional payments from Xxxxx XXXX as a result of any Excusable Failure or to payments for deliverable(s) not provided as a result of the Excusable Failure.


More Definitions of Excusable Failure

Excusable Failure has the meaning given in Section 2.214.
Sample 1Sample 2
Excusable Failure has the meaning given in Section 2.244.
Sample 1

Related to Excusable Failure

  • MI Failure means when an MI report: a) contains any material errors or material omissions or a missing mandatory field; or b) is submitted using an incorrect MI reporting Template; or c) is not submitted by the reporting date(including where a Nil Return should have been filed);

  • GEP Failure means Seller’s failure to produce Delivered Energy in an amount equal to or greater than the Guaranteed Energy Production amount for the applicable Performance Measurement Period.

  • Service Failure means a failure by the Contractor to provide the Services in accordance with any individual service level described above (measured on a monthly/quarterly/annual basis)

  • Force Majeure Failure has the meaning set forth in Section 8.1(d).

  • Volume Failure means, with respect to a particular date of determination, the aggregate daily dollar trading volume (as reported on Bloomberg) of the Common Stock on the Principal Market on any Trading Day during the twenty (20) Trading Day period ending on the Trading Day immediately preceding such date of determination (such period, the “Volume Failure Measuring Period”), is less than $2,000,000 (as adjusted for any stock splits, stock dividends, stock combinations, recapitalizations or other similar transactions occurring after the Subscription Date). All such determinations to be appropriately adjusted for any stock splits, stock dividends, stock combinations, recapitalizations or other similar transactions during such Volume Failure Measuring Period.

  • Price Failure means, with respect to a particular date of determination, the VWAP of the Common Stock on any Trading Day during the seven (7) Trading Day period ending on the Trading Day immediately preceding such date of determination fails to exceed the Floor Price (as adjusted for stock splits, stock dividends, stock combinations, recapitalizations or other similar transactions occurring after the date hereof). All such determinations to be appropriately adjusted for any stock splits, stock dividends, stock combinations, recapitalizations or other similar transactions during any such measuring period.

  • Transaction Failure means the failure to consummate a Business Combination within 18 months of the Effective Date (or 24 months after the Effective Date, if a letter of intent, agreement in principle or definitive agreement has been executed within 18 months after the Effective Date and the Business Combination relating thereto has not yet been consummated within such 18-month period).

  • Epidemic Failure means a series of repeating failures or defects resulting in at least a 0.5% failure rate for the same Product or Material during any twelve-month period.

  • Persistent Failure means any two (2) or more failures by the Supplier in any rolling period of twelve (12) months to comply with obligations in respect of the Contract Services under the Contract;

  • Supply Failure has the meaning given to it in Section 7.5.2 (Supply Failure).

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Milestone Failure means a failure by the Grant Recipient fully to achieve any Milestone by the relevant Milestone Date;

  • Transaction Failure Date means the 18-month anniversary of the Effective Date (or the 24 month anniversary of the Effective Date, if a letter of intent, agreement in principle or definitive agreement has been executed within 18 months after the Effective Date and the Business Combination relating thereto has not yet been consummated within such 18-month period).

  • Technical Failure means the discontinuation of Development or Commercialization of a Product for technical, scientific, medical or regulatory reasons, including, but, not limited to, unacceptable preclinical toxicity, demonstration of a side effect profile significantly worse than currently marketed products, or inability to manufacture in an acceptable purity or for an acceptable price.

  • Consistent Failure means any of:

  • Service Level Failure means a failure to perform the Software Support Services fully in compliance with the Support Service Level Requirements.

  • Potential Failure to Pay means the failure by a Reference Entity to make, when and where due, any payments in an aggregate amount of not less than the Payment Requirement under one or more Obligations, without regard to any grace period or any conditions precedent to the commencement of any grace period applicable to such Obligations, in accordance with the terms of such Obligations at the time of such failure.

  • Listing Failure Event means that:

  • Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.

  • Daily Failure Amount means the product of (x) .005 multiplied by (y) the Closing Sale Price of the Common Stock on the applicable Share Delivery Date.

  • Reporting Failure has the meaning set forth in Section 2.4.

  • Registration Failure means that (A) the Company fails to file with the SEC on or before the Filing Deadline (as defined in the Registration Rights Agreement) any Registration Statement required to be filed pursuant to Section 2(a) of the Registration Rights Agreement, (B) the Company fails to use its best efforts to obtain effectiveness with the SEC, prior to the Registration Deadline (as defined in the Registration Rights Agreement), of any Registration Statement (as defined in the Registration Rights Agreement) that is required to be filed pursuant to Section 2(a) of the Registration Rights Agreement, or fails to use its best efforts to keep each such Registration Statement current and effective as required in Section 3 of the Registration Rights Agreement, (C) the Company fails to file any additional Registration Statement required to be filed pursuant to Section 2(a)(ii) of the Registration Rights Agreement on or before the Additional Filing Deadline or fails to use its best efforts to cause such additional Registration Statement to become effective on or before the Additional Registration Deadline, (D) the Company fails to file any amendment to any Registration Statement, or any additional Registration Statement required to be filed pursuant to Section 3(b) of the Registration Rights Agreement within thirty (30) days of the applicable Registration Trigger Date (as defined in the Registration Rights Agreement), or fails to use its best efforts to cause such amendment and/or new Registration Statement to become effective within ninety (90) days of the applicable Registration Trigger Date, (E) any Registration Statement required to be filed under the Registration Rights Agreement, after its initial effectiveness and during the Registration Period (as defined in the Registration Rights Agreement), lapses in effect or sales of all of the Registrable Securities (as defined in the Registration Rights Agreement) cannot otherwise be made thereunder (whether by reason of the Company’s failure to amend or supplement the prospectus included therein in accordance with the Registration Rights Agreement, the Company’s failure to file and use its best efforts to obtain effectiveness with the SEC of an additional Registration Statement or amended Registration Statement required pursuant to Sections 2(a)(ii) or 3(b) of the Registration Rights Agreement, as applicable, or otherwise), or (F) the Company fails to provide a commercially reasonable written response to any comments to any Registration Statement submitted by the SEC within twenty five (25) days of the date that such SEC comments are received by the Company.

  • Excused Outage means any disruption to or unavailability of Services caused by or due to (i) Scheduled Maintenance,

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Listing Failure means the situation where the Bonds have not been listed on the corporate bond list of Nasdaq Stockholm (or any other Regulated Market) within sixty (60) calendar days after the Issue Date.

  • Excused Downtime means the number of minutes in the Charging Period, rounded to the nearest minute that the link state of Customer’s Port is ‘down’ due to: