Indemnification Claims (a) In the event that any of the Parties are entitled, or seek to assert rights, to indemnification under this Article VI, the Party or Parties seeking indemnification (the “Indemnified Parties”) shall give written notification to the other Party or Parties (the “Indemnifying Parties”) of the commencement of any suit or proceeding relating to a third party claim for which indemnification pursuant to this Article VI may be sought. Such notification shall be given within 20 Business Days after receipt by the Indemnified Parties of notice of such suit or proceeding, and shall describe in reasonable detail (to the extent known by the Indemnified Parties) the facts constituting the basis for such suit or proceeding and the amount of the claimed damages; provided, however, that no delay on the part of the Indemnified Parties in notifying the Indemnifying Parties shall relieve the Indemnifying Parties of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Parties may, upon written notice thereof to the Indemnified Parties seeking indemnification, assume control of the defense of such suit or proceeding with counsel reasonably satisfactory to the Indemnified Party seeking indemnification; provided that the Indemnifying Parties may not assume control of the defense of a suit or proceeding involving criminal liability or in which equitable relief is sought against the Indemnified Party seeking indemnification. If the Indemnifying Parties do not so assume control of such defense, the Indemnified Parties seeking indemnification shall control such defense. The Party not controlling such defense (the “Non-Controlling Party”) may participate therein at its own expense; provided that if the Indemnifying Parties assumes control of such defense and the Indemnified Parties seeking indemnification reasonably concludes that the Indemnifying Parties and the Indemnified Parties seeking indemnification have conflicting interests or different defenses available with respect to such suit or proceeding, the reasonable fees and expenses of counsel to the Indemnified Parties shall be considered “Damages” for purposes of this Agreement. The Party or Parties controlling such defense (the “Controlling Party”) shall keep the Non-Controlling Party advised of the status of such suit or proceeding and the defense thereof and shall consider in good faith recommendations made by the Non-Controlling Party with respect thereto. The Non-Controlling Party shall furnish the Controlling Party with such information as it may have with respect to such suit or proceeding (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party as reasonably needed in the defense of such suit or proceeding at the sole cost and expense of the Indemnifying Parties under Section 6.1 or 6.2, which cost and expense shall be considered “Damages” for purposes of this Agreement. The Indemnifying Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnified Parties, which shall not be unreasonably withheld or delayed; provided that the consent of the Indemnified Parties shall not be required if the Indemnifying Parties agrees in writing to pay any amounts payable pursuant to such settlement or judgment and such settlement or judgment includes a complete release of the Indemnified Parties from further liability and has no other materially adverse effect on the Indemnified Parties. The Indemnified Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnifying Parties, which shall not be unreasonably withheld or delayed.
PATENT INDEMNIFICATION The Contractor agrees to assume the defense of and shall indemnify and save harmless the Owner and all persons acting for or on behalf of it from all suits and claims against them, or any of them, arising from or occasioned by the use of any material, Equipment or apparatus, or any part thereof which infringes or is alleged to infringe on any patent rights. In case such material, equipment or apparatus, or any part thereof, in any such suit is held to constitute infringement, the Contractor, within a reasonable time, shall at its own expense, and as the Owner may elect, replace such material, Equipment or apparatus with non-infringing material, Equipment or apparatus, or remove the material, equipment, or apparatus and refund the sums paid therefor.
NOTICE OF INDEMNIFICATION CLAIMS If the Town seeks indemnification pursuant to this Article 13.2, it shall notify Competitive Supplier of the existence of a claim, or potential claim as soon as practicable after learning of such claim, or potential claim, describing with reasonable particularity the circumstances giving rise to such claim. Upon written acknowledgment by the Competitive Supplier that it will assume the defense and indemnification of such claim, the Competitive Supplier may assert any defenses which are or would otherwise be available to the Town.
Infringement Indemnification If notified promptly in writing of any judicial action brought against City based on an allegation that City’s use of the Licensed Software infringes a patent, copyright, or any right of a third party or constitutes misuse or misappropriation of a trade secret or any other right in intellectual property (Infringement), Contractor will hold City harmless and defend such action at its own expense. Contractor will pay the costs and damages awarded in any such action or the cost of settling such action, provided that Contractor shall have sole control of the defense of any such action and all negotiations or its settlement or compromise. If notified promptly in writing of any informal claim (other than a judicial action) brought against City based on an allegation that City’s use of the Licensed Software constitutes Infringement, Contractor will pay the costs associated with resolving such claim and will pay the settlement amount (if any), provided that Contractor shall have sole control of the resolution of any such claim and all negotiations for its settlement. In the event a final injunction is obtained against City’s use of the Licensed Software by reason of Infringement, or in Contractor’s opinion City’s use of the Licensed Software is likely to become the subject of Infringement, Contractor may at its option and expense: (a) procure for City the right to continue to use the Licensed Software as contemplated hereunder, (b) replace the Licensed Software with a non-infringing, functionally equivalent substitute Licensed Software, or (c) suitably modify the Licensed Software to make its use hereunder non-infringing while retaining functional equivalency to the unmodified version of the Licensed Software. If none of these options is reasonably available to Contractor, then the Agreement may be terminated at the option of either Party hereto and Contractor shall refund to City all amounts paid under this Agreement for the license of such infringing Licensed Software. Any unauthorized modification or attempted modification of the Licensed Software by City or any failure by City to implement any improvements or updates to the Licensed Software, as supplied by Contractor, shall void this indemnity unless City has obtained prior written authorization from Contractor permitting such modification, attempted modification or failure to implement. Contractor shall have no liability for any claim of Infringement based on City’s use or combination of the Licensed Software with products or data of the type for which the Licensed Software was neither designed nor intended to be used.
Licensee Indemnification Licensee will indemnify, defend and hold harmless UM, its trustees, officers, agents and employees (collectively, the “Indemnified Parties”), from and against any and all liability, loss, damage, action, claim or expense suffered or incurred by the Indemnified Parties which results from or arises out of third party claims in connection with (individually, a “Liability” and collectively, the “Liabilities”):
Defense and Indemnification a. The Contractor hereby agrees to defend, indemnify, reimburse and hold harmless the City, its appointed and elected officials, agents and employees for, from and against all liabilities, claims, judgments, suits or demands for damages to persons or property arising out of, resulting from, or relating to the work performed under this Agreement (“Claims”), unless such Claims have been specifically determined by the trier of fact to be the sole negligence or willful misconduct of the City. This indemnity shall be interpreted in the broadest possible manner to indemnify the City for any acts or omissions of the Contractor or its subcontractors either passive or active, irrespective of fault, including the City’s concurrent negligence whether active or passive, except for the sole negligence or willful misconduct of the City.
INSURANCE/INDEMNIFICATION A. The School agrees to provide the following proof of insurance:
Client Indemnification Client shall defend MRI against any claim, demand, suit, or proceeding made or brought against MRI by a third party arising out of or related to (i) the Client Data; (ii) Client’s or its users’ use of the Software or the SaaS Services in violation of the Agreement; (iii) Client or any user infringing or misappropriating the Intellectual Property rights of a third party or violating applicable law; or (iv) Client’s or its users’ use or misuse of the Software or SaaS Service or Client’s or its users’ use or misuse of the Client Data (including, without limitation, accessing, providing access, using or distributing the Client Data) (each of the above a “Client Claim”). Client shall indemnify MRI for all damages and costs finally awarded against, and for reasonable attorneys’ fees incurred by, MRI in connection with any Client Claim, or those costs and damages agreed to in a monetary settlement of such Client Claim; provided that MRI (a) promptly gives Client written notice of the Client Claim, (b) gives Client sole control of the defence and settlement of the Client Claim (provided that Client may not settle or defend any Client Claim unless it unconditionally releases MRI of all liability), and (c) provides Client all reasonable assistance, at Client’s cost. For purposes of this Section 7.4 only, “MRI” shall include MRI and its Affiliates, and each of their members, owners, officers, directors, employees, agents, successors and assigns.
Survival Indemnification All representations, warranties and covenants contained in this Agreement and the indemnification contained herein shall survive (a) the acceptance of this Agreement by the Company, (b) changes in the transactions, documents and instruments described herein which are not material or which are to the benefit of Subscriber, and (c) the death or disability of Subscriber. Subscriber acknowledges the meaning and legal consequences of the representations, warranties and covenants in Article II hereof and that the Company has relied upon such representations, warranties and covenants in determining Subscriber's qualification and suitability to purchase the Securities. Subscriber hereby agrees to indemnify, defend and hold harmless the Company, its officers, directors, employees, agents and controlling persons, from and against any and all losses, claims, damages, liabilities, expenses (including attorneys' fees and disbursements), judgments or amounts paid in settlement of actions arising out of or resulting from the untruth of any representation of Subscriber herein or the breach of any warranty or covenant herein by Subscriber. Notwithstanding the foregoing, however, no representation, warranty, covenant or acknowledgment made herein by Subscriber shall in any manner be deemed to constitute a waiver of any rights granted to it under the Securities Act or state securities laws.
Union Indemnification In consideration of full and active participation by the member organizations of the Coalition in the WPS program, and in recognition of the potential liability which might result solely from that participation, Kaiser Foundation Hospitals and Kaiser Foundation Health Plan, Inc. agree that they, or one of the subsidiary health plan organizations of Xxxxxx Foundation Health Plan, Inc., will indemnify Coalition unions and their officers and employees, and hold them harmless against any and all suits, claims, demands and liabilities arising from or relating to their participation in WPS with Xxxxxx Permanente.
