Termination in the Event of Delayed Notice to Proceed Sample Clauses

Termination in the Event of Delayed Notice to Proceed. In the event Owner fails to issue the NTP in accordance with Section 5.2B by December 31, 2013 (as may be extended by mutual agreement by the Parties), then either Party shall have the right to terminate this Agreement by providing written notice of termination to the other Party, to be effective upon receipt by the other Party. In the event of such termination, Contractor shall have the rights (and Owner shall make the payments) provided for in Section 16.2, except that, in respect of loss of profit, Contractor shall only be entitled to a lump sum equal to Five Million U.S. Dollars (U.S.$ 5,000,000).
Sample 1Sample 2Sample 3See All (20)
AutoNDA by SimpleDocs
Termination in the Event of Delayed Notice to Proceed. Contractor may terminate this Agreement pursuant to Section 5.2E.3.
Sample 1
Termination in the Event of Delayed Notice to Proceed. In the event Owner fails to issue the NTP for Subproject 6(a) in accordance with Section 5.2A by February 2, 2021 (as may be extended by mutual agreement by the Parties), then either Party shall have the right to terminate this Agreement by providing written notice of termination to the other Party, to be effective upon receipt by the other Party. In the event of such termination, Contractor shall have the rights (and Owner shall make the payments) provided for in Section 16.2, except that, in respect of loss of profit, Contractor shall only be entitled to a lump sum equal to Five Million U.S. Dollars (U.S.$5,000,000).
Sample 1

Related to Termination in the Event of Delayed Notice to Proceed

  • Termination in the Event of Death or Disability This Agreement shall terminate in the event of death or disability of Executive.

  • Termination Notice If either Party, having become entitled to do so, decides to terminate this Agreement pursuant to the preceding Clause 8.2 (a) (i) or 8.2 (a) (ii), it shall issue Termination Notice setting out:

  • CONTRIBUTION IN THE EVENT OF JOINT LIABILITY (a) To the fullest extent permissible under applicable law, if the indemnification, hold harmless and/or exoneration rights provided for in this Agreement are unavailable to Indemnitee in whole or in part for any reason whatsoever, the Company, in lieu of indemnifying, holding harmless or exonerating Indemnitee, shall pay, in the first instance, the entire amount incurred by Indemnitee, whether for judgments, liabilities, fines, penalties, amounts paid or to be paid in settlement and/or for Expenses, in connection with any Proceeding without requiring Indemnitee to contribute to such payment, and the Company hereby waives and relinquishes any right of contribution it may have at any time against Indemnitee.

  • Termination Giving Rise to a Termination Payment If there is a Covered Termination by the Executive for Good Reason, or by the Company other than by reason of (i) death, (ii) disability pursuant to Section 11, or (iii) Cause, then the Executive shall be entitled to receive, and the Company shall promptly pay, Accrued Benefits and, in lieu of further base salary for periods following the Termination Date, as liquidated damages and additional severance pay and in consideration of the covenant of the Executive set forth in Section 13(a), the Termination Payment pursuant to Section 8(a).

  • Initiation; Confirmation; Termination (a) An agreement to enter into a Transaction may be made orally or in writing at the initiation of either Buyer or Seller. On the Purchase Date for the Transaction, the Purchased Securities shall be transferred to Buyer or its agent against the transfer of the Purchase Price to an account of Seller.

  • Termination Event; Notice The Purchase Contracts and all obligations and rights of the Company and the Holders thereunder, including, without limitation, the rights of the Holders to receive and the obligation of the Company to pay any Purchase Contract Payments (including any deferred or accrued and unpaid Purchase Contract Payments), if the Company shall have such obligation, and the rights and obligations of Holders to purchase Common Stock, shall immediately and automatically terminate, without the necessity of any notice or action by any Holder, the Purchase Contract Agent or the Company, if, prior to or on the Purchase Contract Settlement Date, a Termination Event shall have occurred.

  • Termination Following a Change of Control If the Employee's employment terminates at any time within eighteen (18) months following a Change of Control, then, subject to Section 5, the Employee shall be entitled to receive the following severance benefits:

  • Termination in Connection with Change of Control If Executive’s employment is terminated by the Company without Cause or by Executive for Good Reason within sixty (60) days prior to or twelve (12) months following a Change of Control, Executive shall be entitled to receive, in lieu of any severance benefits to which Executive may otherwise be entitled under any severance plan or program of the Company, the benefits provided below:

  • Termination After Change of Control In the event that, before the expiration of the TERM and in connection with or within one year of a CHANGE OF CONTROL (as defined hereinafter) of either one of the EMPLOYERS, the employment of the EMPLOYEE is terminated for any reason other than JUST CAUSE or is terminated by the EMPLOYEE as provided in Section 4(a)(ii) above, then the following shall occur:

Time is Money Join Law Insider Premium to draft better contracts faster.