Cost of Repairs 54.1 Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor's cost if the loss or damage arises from the Contractor's acts or omissions.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
DAMAGE OR DESTRUCTION OF PREMISES (a) If the Premises or any part thereof shall be damaged by fire or other insured casualty, then, subject to the last paragraph of this Section, Landlord shall proceed with diligence, subject to then applicable statutes, building codes, zoning ordinances and regulations of any governmental authority, and at the expense of Landlord (but only to the extent of insurance proceeds made available to Landlord by any mortgagee of the Building and any ground lessor) to repair or cause to be repaired such damage (other than any Initial Tenant Improvements not deemed to be fixtures covered by Landlord’s property insurance and Tenant Work, which Tenant shall promptly commence, and proceed with diligence, to restore). All such repairs made necessary by any act or omission of Tenant shall be made at the Tenant’s expense to the extent that the cost of such repairs are less than the deductible amount in Landlord’s insurance policy. All repairs to and replacements of Tenant Property not deemed to be fixtures covered by Landlord’s property insurance and any Initial Tenant Improvements and Tenant Work shall be made by and at the expense of Tenant. The cost of any repairs performed under this Section by Landlord at Tenant’s request and at Tenant’s expense (including costs of design fees, financing, and charges for administration, overhead and construction management services by Landlord and Landlord’s contractor) shall constitute Additional Rent hereunder. If the Premises or any part thereof shall have been rendered unfit for use and occupation hereunder by reason of such damage, the Base Rent or a just and proportionate part thereof, according to the nature and extent to which the Premises shall have been so rendered unfit, shall be abated until the Premises (except as to Tenant Property, Initial Tenant Improvements not deemed to be fixtures covered by Landlord’s property insurance and any Tenant Work) shall have been restored as nearly as practicable to the condition in which they were immediately prior to such fire or other casualty; and that if and to the extent Landlord shall be unable to collect the insurance proceeds (including rent insurance proceeds) applicable to such damage because of some action or inaction on the part of Tenant, or the employees, licensees or invitees of Tenant, the cost of repairing such damage shall be paid by Tenant and there shall be no abatement of rent. Landlord shall not be liable for delays in the making of any such repairs that are due to government regulation, casualties, and strikes, unavailability of labor and materials, delays in obtaining insurance proceeds, and other causes beyond the reasonable control of Landlord, nor shall Landlord be liable for any inconvenience or annoyance to Tenant or injury to the business of Tenant resulting from delays in repairing such damage. If the Premises or the Building are substantially damaged so as to prevent Tenant from using the Premises for the Permitted Use and the Premises have not been restored to the condition required pursuant to the terms of this Lease within two hundred and seventy (270) days following said casualty (or if such casualty occurs during the last 18 months of the term, within ninety (90) days after the date of such casualty), then Tenant may terminate this Lease upon thirty (30) days written notice to Landlord unless Landlord shall substantially complete such repair and restoration within such thirty (30) day period in which event Tenant’s termination shall be void and of no further force or effect.
Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Reasonable Repairs a. We will pay the reasonable cost incurred by you for the necessary measures taken solely to protect covered property that is damaged by a Peril Insured Against from further damage.
Damage, Destruction or Condemnation If the Dock or any portion thereof is at any time destroyed or damaged by a casualty, or if any portion of the Dock or adjacent parcels are taken pursuant to the exercise or threatened exercise of the power of eminent domain (including a conveyance in lieu thereof), Port may elect to terminate this Agreement.
Repair Concessionaire shall, prior to the commencement of the Concession Operation under the Agreement, provide to Department a type-written concession equipment maintenance plan for the State-owned equipment located on the Concession Premises, together with a schedule for preventative maintenance and a report on maintenance completion and equipment condition. Failure to comply with this preventative maintenance schedule shall result in Concessionaire being responsible for all repairs and/or replacement of equipment. The review and Department inspection of the Concession Premises and its equipment will be conducted during routine inspection of the Concession Premises and as a part of the Mandatory Compliance and Performance Evaluation Meetings.
Damage or Destruction 17.1 If the Premises or the Building are totally or partially damaged or destroyed thereby rendering the Premises totally or partially inaccessible or unusable, then Landlord shall diligently repair and restore the Premises and the Building to substantially the same condition they were in prior to such damage or destruction; provided, however, that if in Landlord’s reasonable judgment such repair and restoration cannot be completed within two hundred seventy (270) days after the occurrence of such damage or destruction (taking into account the time needed for effecting a satisfactory settlement with any insurance company involved, removal of debris, preparation of plans and issuance of all required governmental permits), then Landlord shall have the right to terminate this Lease by giving written notice of termination within forty five (45) days after the occurrence of such damage or destruction. If this Lease is terminated pursuant to this Article, then rent shall be apportioned (based on the portion of the Premises which is usable or used after such damage or destruction) and paid to the later of the date of termination or the date Tenant completely vacates and abandons the Premises on account of such damage and (if applicable) Landlord shall be entitled to any insurance proceeds received by Tenant that are attributable to Landlord’s Work and other improvements insured or required to be insured by Tenant that would remain in the Premises at the end of the Lease Term. If this Lease is not terminated as a result of such damage or destruction, then until such repair and restoration of the Premises are substantially complete, Tenant shall be required to pay rent only for the portion of the Premises that is usable while such repair and restoration are being made; provided, however, that (x) if such damage or destruction was caused by the act or omission of Tenant or any Agent of Tenant, then Tenant shall not be entitled to any such rent reduction and (y) if Tenant fails to immediately pay over to Landlord insurance proceeds when received from Tenant’s insurance any such rent abatement shall end on the date when Landlord would have been able to substantially complete repair and restoration of the Premises had Tenant timely paid Landlord such insurance proceeds. After receipt of all insurance proceeds (including proceeds of insurance maintained by Tenant), Landlord shall proceed with and bear the expenses of such repair and restoration of the Premises and the Building; provided, however, that (a) if such damage or destruction was caused by the act or omission of Tenant or any Agent of Tenant, then Tenant shall pay Landlord’s deductible and the amount by which such expenses exceed the insurance proceeds, if any, actually received by Landlord on account of such damage or destruction (or, if Landlord fails to maintain the insurance required by Section 13.3, that Landlord would have received had Landlord maintained such insurance required by Section 13.3), (b) Tenant shall pay the amount by which the cost of restoring any item which Landlord is required to restore and Tenant is required to insure exceeds the insurance proceeds received with respect thereto, and (c) Landlord shall not be required to repair or restore any tenant improvements installed in the Premises (except to the extent Landlord receives proceeds therefor from Tenant’s insurance), any Alterations or any other contents of the Premises (including Tenant’s trade fixtures, decorations, furnishings, equipment or personal property). Notwithstanding anything herein to the contrary, Landlord shall have the right to terminate this Lease if (1) insurance proceeds plus deductibles are insufficient to pay the full cost of such repair and restoration (so long as Landlord maintains the insurance required by Section 13.3), (2) the holder of any Mortgage fails or refuses to make such insurance proceeds available for such repair and restoration, (3) zoning or other applicable Laws or regulations do not permit such repair and restoration, or (4) the damage to the Building exceeds thirty five percent (35%) of the replacement value of the Building.
MAINTENANCE, REPAIRS, OR ALTERATIONS The Tenant shall, at their own expense and at all times, maintain premises in a clean and sanitary manner, and shall surrender the same at termination hereof, in as good condition as received, normal wear and tear excepted. The Tenant may not make any alterations to the leased premises without the consent in writing of the Landlord. The Landlord shall be responsible for repairs to the interior and exterior of the building. If the Premises includes a washer, dryer, freezer, dehumidifier unit and/or air conditioning unit, the Landlord makes no warranty as to the repair or replacement of units if one or all shall fail to operate. The Landlord will place fresh batteries in all battery-operated smoke detectors when the Tenant moves into the premises. After the initial placement of the fresh batteries it is the responsibility of the Tenant to replace batteries when needed. A monthly "cursory" inspection may be required for all fire extinguishers to make sure they are fully charged.
Maintenance, Alteration and Repair (a) Resident is responsible for and agrees to take good care of the premises, fixtures and all common areas. Resident may not remove any of Owner’s property and will not perform any repairs, upgrades, painting, wallpapering, electric changes or other alterations of the premises without prior written consent from Owner. Resident will be responsible for damage from waste stoppages caused by foreign or improper objects or improper use in lines serving bathrooms, damage to fixtures, appliances, doors, windows, screens, damage from water faucets left on or from doors left open, and repairs or replacements to alarm devices necessitated by misuse or damage by Resident and/or guests. Extraordinary appliances or furnishings such as satellite dishes, hot tubs, pool tables, water beds or high utility-consuming devices may not be installed or placed on the premises or anywhere at the Property without Owner’s prior written consent, in its sole discretion. SAMPLE
