Tenant Improvements Subject to this Section 4, Tenant shall accept the Suite 110 Premises in its “as is” condition (subject to Landlord's continuing repair and maintenance obligations, as outlined in Section 10 of the Lease (as may be amended)), and Landlord shall have no obligation to make any alterations or improvements thereto whatsoever (provided that Landlord shall deliver same in good and tenantable condition, broom clean, with all systems serving same in good working order). Any alterations that Tenant desires to make in the Suite 110 Premises shall be subject to all the terms and conditions set forth in Section 11 of the Lease. Notwithstanding anything in the Lease to the contrary, Landlord hereby agrees to grant Tenant an allowance in the amount of $10,000 to be applied toward the cost (including architectural and engineering fees) of alterations performed by Tenant in the Suite 110 Premises (the “Granted Allowance”) in conjunction with Tenant’s initial occupancy of Suite 110 Premises. Provided no Event of Default then exists under the Lease, the Granted Allowance (or portions thereof) shall be disbursed to Tenant within thirty (30) days following Tenant's submission to Landlord of paid invoices for work related to alterations performed by Tenant in the Suite 110 Premises, accompanied by waivers of liens executed by all contractors employed by Tenant for the performance of such work. If the cost of Tenant's alterations in the Suite 110 Premises exceeds the amount of the Granted Allowance, the excess shall be paid by Tenant after the Granted Allowance is fully exhausted. Any portion of the Granted Allowance that has not been applied (or contracted to be applied) in the manner set forth above by the date which is twelve (12) months following the Eighth Amendment Commencement Date shall revert to Landlord, and Tenant shall have no further rights with respect thereto.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
Multi-Tenant Floors If other tenants occupy space on the floor on which the Premises is located, Tenant’s identifying signage shall be provided by Landlord, at Tenant’s cost, and such signage shall be comparable to that used by Landlord for other similar floors in the Building and shall comply with Landlord’s then-current Building standard signage program.
Landlord Improvements Landlord shall substantially complete the Landlord Improvements prior to Tenant’s taking occupancy of the Expansion Space. Landlord shall use commercially reasonable efforts to complete the Landlord Improvements by May 1, 2014. “Substantial Completion” shall mean the Landlord Improvements have been constructed in material accordance with the above referenced drawing, save and except for minor “punch list” items such that Tenant can occupy the Expansion Space and conduct its business, Landlord has obtained all approvals from the applicable governmental authorities for the legal occupancy of the Expansion Space and Landlord has delivered possession of the Expansion Space to Tenant in the required condition, which date is currently anticipated to be May 1, 2014. Upon Substantial Completion, Landlord shall deliver possession of the Expansion Space to Tenant in good, vacant, broom clean condition, with all building systems in good working order and the roof water-tight, and in compliance with all laws applicable to Landlord or Tenant. In the event that construction of the Landlord Improvements is not substantially completed by May 1, 2014, then the Expansion Space Commencement Date shall be automatically amended to be that date the Expansion Space is delivered to Tenant with the Landlord Improvements substantially complete. Upon Substantial Completion of the Landlord Improvements, Landlord shall give Tenant (i) written notice (“Notice of Completion”) that the Expansion Space are ready for occupancy. Within seven (7) days following Landlord’s giving of the Notice of Completion, Landlord and Tenant shall meet at a mutually convenient time to perform a walk-through of the Expansion Space to inspect the Landlord Improvements and to prepare a punch list of minor items needing correction and Landlord shall promptly cause such items to be corrected.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Building Renovations It is specifically understood and agreed that Landlord has made no representation or warranty to Tenant and has no obligation and has made no promises to alter, remodel, improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Premises or the Building have been made by Landlord to Tenant except as specifically set forth herein or in the Work Letter Agreement. However, Tenant hereby acknowledges that Landlord is currently renovating or may during the Lease Term renovate, improve, alter, or modify (collectively, the "Renovations") the Project, the Building and/or the Premises including without limitation the parking structure, common areas, systems and equipment, roof, and structural portions of the same, which Renovations may include, without limitation, (i) installing sprinklers in the Building common areas and tenant spaces, (ii) modifying the common areas and tenant spaces to comply with applicable laws and regulations, including regulations relating to the physically disabled, seismic conditions, and building safety and security, and (iii) installing new floor covering, lighting, and wall coverings in the Building common areas, and in connection with any Renovations, Landlord may, among other things, erect scaffolding or other necessary structures in the Building, limit or eliminate access to portions of the Project, including portions of the common areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Tenant hereby agrees that such Renovations and Landlord's actions in connection with such Renovations shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of Rent. Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant's business arising from the Renovations, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant's personal property or improvements resulting from the Renovations or Landlord's actions in connection with such Renovations, or for any inconvenience or annoyance occasioned by such Renovations or Landlord's actions.
Landlord’s Insurance Tenant shall not cause or permit or suffer any action or condition that would (i) invalidate or conflict with Landlord’s insurance policies which contemplate a live entertainment use for the Music Hall, (ii) violate applicable rules, regulations and guidelines of the Fire Department, Fire Insurance Rating Organization or any other authority having jurisdiction over the Center, (iii) cause an increase in the premiums for fire insurance then covering the Buildings over that payable with respect to comparable first-class office buildings or theaters, or (iv) result in insurance companies of good standing refusing to insure the Buildings or any property therein in amounts and against risks as reasonably determined by Landlord. If the fire insurance premiums increase as a result of Tenant’s failure to comply with the provisions of this Article, Tenant shall promptly cure such failure and shall reimburse Landlord for the increased fire insurance premiums paid by Landlord as a result of such failure by Tenant, provided that Landlord shall furnish reasonable supporting documentation therefor. If it is not practicable for Tenant to cure such failure and continue to operate the Premises for the Permitted Uses and the only result of such failure is an increase in Landlord’s insurance premium, then provided Tenant pays such increased premium, Tenant shall not be required to cease such action so long as the increased premium is the only effect of such failure and, provided further, in the event that (A) Landlord’s insurance carrier refuses to provide certain insurance as a result of Tenant’s failure to comply with the provisions of this Article and (B) a separate insurance carrier of comparable rating or which is otherwise satisfactory to Landlord is willing to provide such insurance, Tenant shall pay any increased cost payable by Landlord by reason of its purchase of such insurance from such separate insurance carrier. In any action or proceeding to which Landlord and Tenant are parties, a schedule or “make up” of rates for the Buildings or the Premises issued by the appropriate Fire Insurance Rating Organization, or other body fixing such fire insurance rates, shall be conclusive evidence of the fire insurance rates then applicable to the Buildings.
TENANT'S USE OF THE PREMISES In consideration of the agreements contained herein, Landlord hereby leases the Premises to Tenant, and Tenant hereby leases the Premises from Landlord, for the Term and upon the terms and conditions hereinafter provided. The Premises are leased subject to, and Tenant agrees not to violate, all present and future covenants, conditions and restrictions of record which affect the Land, all of such documents collectively referred to as the "Restrictions". As an appurtenance to the Premises, Tenant shall have the general and nonexclusive right, together with Landlord and the other tenants of the Project and their respective agents, to use the Common Area subject to the terms and conditions of this Lease. Tenant shall use the Premises solely for the purpose set forth in Tenant's Use Clause as designated in Article 2.n and for no other purpose. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall by reason of the nature of Tenant's use or occupancy of the Promises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Board of Fire Insurance underwriters or any other organization performing a similar function. Tenant shall promptly upon demand reimburse Landlord for any additional premium charged for such policy by reason of Tenant's failure to comply with the provisions of this Article. Tenant shall not do or permit anything to be done in or about the Premises which will in any way obstruct or interfere with the rights of other tenants or occupants of the Building or Project, or injure or annoy them, or use or allow the Premises to be used for any improper, immoral, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance in, on or about the Premises. Tenant shall not commit or suffer to be committed any waste in or upon the Premises. Tenant acknowledges that Tenant assumes all responsibility regarding the Occupational Safety Health Act, the legal use and adaptability of the Premises and the compliance thereof with all applicable laws and regulations in effect during the form of this Lease.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
