Delays during construction Without prejudice to the provisions of Clause 10.3 (ii), in the event the Contractor does not achieve any of the Project Milestones or the Authority’s Engineer shall have reasonably determined that the rate of progress of Works is such that Completion of the Project Highway is not likely to be achieved by the end of the Scheduled Completion Date, it shall notify the same to the Contractor, and the Contractor shall, within 15 (fifteen) days of such notice, by a communication inform the Authority’s Engineer in reasonable detail about the steps it proposes to take to expedite progress and the period within which it shall achieve the Project Completion Date.
Maintenance during Construction Period (i) During the Construction Period, the Contractor shall maintain, at its cost, the existing lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at no time materially inferior as compared to their condition on Appointed Date, and shall undertake the necessary repair and maintenance works for this purpose; provided that the Contractor may, at its cost, interrupt and divert the flow of traffic if such interruption and diversion is necessary for the efficient progress of Works and conforms to Good Industry Practice; provided further that such interruption and diversion shall be undertaken by the Contractor only with the prior written approval of the Authority’s Engineer which approval shall not be unreasonably withheld. For the avoidance of doubt, it is agreed that the Contractor shall at all times be responsible for ensuring safe operation of the Project Highway. It is further agreed that in the event the Project includes construction of a bypass or tunnel and realignment of the existing carriageway, the Contractor shall maintain the existing highway in such sections until the new Works are open to traffic.
Program Requirements Provided At No Charge to the Judicial Council A. The Contractor shall provide the following items during the Program at no charge to the Judicial Council:
PRE-CONSTRUCTION PHASE FEE The Pre-Construction Phase Fee is the total compensation payable to Contractor for the performance of Pre-Construction Phase Services, except for Additional Pre-Construction Phase Services approved in advance and in writing by Owner. The Pre-Construction Phase Fee shall be a lump sum amount based on the AACC established in this Agreement.
Security Constrained Unit Commitment Adjustments The NTO shall coordinate with its ITO(s) as applicable regarding any request for commitment of additional Generators. If, following coordination among the NTO and its ITO(s), an additional resource(s) needs to be committed to ensure local area reliability, the NTO, or the ITO(s) at the NTO’s request, may request commitment of additional Generators (including specific output level(s)). The ISO will use Supplemental Resource Evaluation (“SRE”), pursuant to ISO Tariffs and ISO Procedures, to fulfill a request from the NTO or ITO(s), as appropriate, for additional units.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
During Construction Upon request of the Owner the Contractor shall submit written proposals for unit prices to be applied in the event Change Order Work is authorized by the Owner to be performed under Case (b).
Services Available or Provided from Other Sources Services for any condition, illness, or disease which should be covered by the United States government or any of its agencies, Medicare, any state or municipal government or any of its agencies except emergency care when there is a legal responsibility to provide it. • Services or supplies for military-related conditions, such as war, or any military action, which takes place after your coverage becomes effective. • Services received in a facility mainly meant to care for students, faculty, or employees of a college or other institution of learning. • Covered healthcare services provided to you when there is no charge to you or there would have been no charge to you absent this health plan. • Services if another entity or agency is responsible under state or federal laws, which are provided for the health of schoolchildren or children with disabilities. See Title 16, Chapters 21, 24, 25, and 26 of the R.I. General Laws. See also applicable regulations about the health of schoolchildren and the special education of children with disabilities or similar rules set forth by federal law or state law of applicable jurisdiction. • Services and supplies which are required under the laws of a state, other than Rhode Island, and are not provided under this health plan. All Other Exclusions • Services not approved by the FDA or other governing body. • Services we have not reviewed or we have not determined are eligible for coverage. • Services obtained through fraud or intentional misrepresentation. • Administrative service charges for: o missed appointments; o completion of claim forms; o additional fees, sometimes referred to as access fees, associated with concierge, boutique, or retainer practices; and o any other administrative charges. • Blood services for drawing, processing, or storage of your own blood, including any penalty fees related to blood services. • Continuation of a covered healthcare service or benefit as a result of a clerical error. • Custodial care, rest care, day care, or non-skilled care services. • Convalescent homes, nursing homes including non-skilled care, assisted living facilities, or other residential facilities. • Educational classes, unless listed as covered, and training services. • Exams or services that are required for or related to employment, education, marriage, adoption, insurance purposes, court order, or similar third parties when not medically necessary or when the benefit limit for the exam or service has been met. • Routine foot care, including the treatment of corns, bunions except capsular or bone surgery, calluses, the trimming of nails, the treatment of simple ingrown nails and other preventive hygienic procedures, except when performed to treat diabetic related nerve and circulation disorders of the feet. • Treatment of flat feet unless the treatment is a covered surgical service. • Telephone consultations, telephone services, or medication monitoring by phone, except for clinically appropriate telemedicine services as described in Section 3. • Healthcare services for work-related illnesses or injuries for which benefits are available under Workers’ Compensation , whether or not you are entitled to such benefits, unless: o you are self-employed, a sole stockholder of a corporation, or a member of a partnership; and o your illnesses or injuries were incurred in the course of your self-employment, sole stockholder, or partnership activities; and o you are not enrolled as an employee under a group health plan sponsored by another employer. • Services and supplies used for your personal appearance and/or comfort, whether or not prescribed by a physician and regardless of your condition. These services and supplies include, but are not limited to: o batteries, unless indicated as covered;
OPERATION OF PROPERTY DURING AGREEMENT PERIOD The Seller will continue to operate the Property and any business conducted on the Property in the manner operated prior to the Agreement and will take no action that would adversely impact the Property, tenants, lender, or business, if any. Any changes, such as renting vacant space, that materially affects the Property or the Buyer's intended use will be permitted only with the Buyer's consent.
General Construction Obligations (a) Without limiting Section 10.3:
