Selection of Contractors and Subcontractors Sample Clauses

Selection of Contractors and Subcontractors. Before commencing construction of any Alterations, Tenant shall submit to Landlord the names of Tenant’s general contractor (the “General Contractor”) and subcontractors for Landlord’s approval. If Landlord shall reject the General Contractor or any subcontractor, Landlord shall advise Tenant of the reasons(s) in writing and Tenant shall submit another selection to Landlord for Landlord’s approval.
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs
Selection of Contractors and Subcontractors. Before commencing construction of any Alterations, Tenant shall submit to Landlord the names of Tenant's general contractor (the "General Contractor") and any subcontractors performing work on the electrical, mechanical, plumbing or life-safety systems of the Building for Landlord's approval, such approval not to be unreasonably withheld, conditioned or delayed. If Landlord shall reject the General Contractor or any such subcontractor, Landlord shall advise Tenant of the reasons(s) in writing and Tenant shall submit another selection to Landlord for Landlord's approval, such approval not to be unreasonably withheld, conditioned or delayed.
Sample 1Sample 2
Selection of Contractors and Subcontractors. Tenant is entitled to use contractors and subcontractors of its choosing for Tenant’s New Improvement Work, and such contractors and subcontractors need not be members of any trade unions.
Sample 1
Selection of Contractors and Subcontractors. Before commencing construction of any Alterations, Tenant shall submit to Landlord the names of Tenant’s general contractor (the “General Contractor”) and any subcontractors for Landlord’s approval (such approval not to be unreasonably withheld, conditioned or delayed). If Landlord shall reject the General Contractor or any subcontractor, Landlord shall within ten (10) business days advise Tenant of the reasons(s) in writing and Tenant shall submit another selection to Landlord for Landlord’s approval.
Sample 1
Selection of Contractors and Subcontractors. Tenant's selection ------------------------------------------- of a general contractor and any subcontractors to construct any alterations and any replacement thereof from time to time, shall be subject to the reasonable consent of Landlord, which consent shall not be unreasonably withheld or delayed.
Sample 1
Selection of Contractors and Subcontractors. Before commencing construction of any Alterations, Tenant shall submit to Landlord the names of Tenant’s general contractor (the “General Contractor”) and subcontractors for Landlord’s approval. If Landlord shall reject the General Contractor or any subcontractor, Landlord shall advise Tenant of the reasons(s) in writing and Tenant shall (with respect to Tenant’s Plans) or may (with respect to proposals that are not part of Tenant’s Plans) submit another selection to Landlord for Landlord’s approval; provided, however, in no event shall Tenant cause to be performed any Alterations other than by a General Contractor that has been approved by Landlord.
Sample 1
Selection of Contractors and Subcontractors. The Borrower has accepted, and hereby accepts, the full responsibility for the selection of its Contractor and subcontractors and all materials, supplies and equipment to be used in the construction of the Improvements, and the Lender assumes no responsibility for the completion of the Improvements, according to the plans and specifications and for the contract price.
Sample 1
AutoNDA by SimpleDocs

Related to Selection of Contractors and Subcontractors

  • Subcontractors 1. FAS may without further consent on the part of the Investment Company at FAS’s own expense, subcontract for the performance of Administrative Services with a sub-contractor selected by FAS. FAS shall be as fully responsible to the Investment Company for the acts and omissions of any subcontractor as it is for its own acts and omissions.

  • Use of Subservicers and Subcontractors The Servicer shall not hire or otherwise utilize the services of any Subservicer to fulfill any of the obligations of the Servicer as servicer under this Agreement or any Reconstitution Agreement unless the Servicer complies with the provisions of paragraph (a) of this Section. The Servicer shall not hire or otherwise utilize the services of any Subcontractor, and shall not permit any Subservicer to hire or otherwise utilize the services of any Subcontractor, to fulfill any of the obligations of the Servicer as servicer under this Agreement or any Reconstitution Agreement unless the Servicer complies with the provisions of paragraph (b) of this Section.

  • Contractors and subcontractors shall establish and maintain a written sexual harassment policy and shall inform their employees of the policy. The policy must contain a notice that sexual harassment will not be tolerated and employees who practice it will be disciplined.

  • Employees and Contractors The number of employees or contractors used by Operator in conducting operations hereunder, their selection, and the hours of labor and the compensation for services performed shall be determined by Operator, and all such employees or contractors shall be the employees or contractors of Operator.

  • Use of Affiliated Companies and Subcontractors In connection with the services to be provided by Manager under this Agreement, Manager may, to the extent it deems appropriate, and subject to compliance with the requirements of applicable laws and regulations, make use of (i) its affiliated companies and their directors, trustees, officers, and employees and (ii) subcontractors selected by Manager, provided that Manager shall supervise and remain fully responsible for the services of all such third parties in accordance with and to the extent provided by this Agreement. All costs and expenses associated with services provided by any such third parties shall be borne by Manager or such parties.

  • Sub-contractors Transfer Agent may, without further consent on the part of Customer, subcontract with other subcontractors for telephone and mailing services as may be required from time to time; provided, however, that the Transfer Agent shall be as fully responsible to the Customer for the acts and omissions of any subcontractor as it is for its own acts and omissions.

  • Use of Subcontractors (a) [Reserved].

  • Subcontractors and Unaffiliated Third Parties (a) The Escrow Agent may, without further consent of any party hereto, subcontract with (i) any of its affiliates, or (ii) unaffiliated subcontractors for such services as may be required from time to time (e.g., lost stockholder searches, escheatment, telephone and mailing services); provided, however, that the Escrow Agent (i) shall be fully responsible for the acts and omissions of its affiliate as it is for its own acts and omissions and (ii) shall not be liable for the acts and omissions of any subcontractor absent willful misconduct, bad faith or gross negligence of the Escrow Agent in the selection of such subcontractor (each as determined by a final, non-appealable judgment of a court of competent jurisdiction).

  • Succession; Subcontractors (a) As a condition to the succession to the Master Servicer and Special Servicer or to any Sub-Servicer (but only if such Sub-Servicer is a Servicing Function Participant and a servicer as contemplated by Item 1108(a)(2)) as servicer or sub-servicer under this Agreement by any Person (i) into which the Master Servicer and Special Servicer or such Sub-Servicer may be merged or consolidated, or (ii) which may be appointed as a successor to the Master Servicer and Special Servicer or to any such Sub-Servicer, the person removing and replacing the Master Servicer and Special Servicer shall provide to the Depositor and the Certificate Administrator, at least fifteen (15) calendar days prior to the effective date of such succession or appointment (or such shorter period as is agreed to by the Depositor), (x) written notice to the Depositor of such succession or appointment and (y) in writing and in form and substance reasonably satisfactory to the Depositor, all information relating to such successor reasonably requested by the Depositor in order to comply with its reporting obligation under Item 6.02 of Form 8-K pursuant to the Exchange Act (if such reports under the Exchange Act are required to be filed under the Exchange Act); provided, however that if disclosing such information prior to such effective date would violate any applicable law or confidentiality agreement, the Master Servicer, the Special Servicer or any Additional Servicer, as the case may be, shall submit such disclosure to the Depositor no later than the first Business Day after the effective date of such succession or appointment.

  • Use by Agents, Employees, Subcontractors The parties shall take reasonable measures to prevent its Agents, employees and subcontractors from using or disclosing any Confidential Information, except as may be necessary for each party to perform its obligations pursuant to this Agreement. Such measures shall include, but not be limited to, (i) education of such Agents, employees and subcontractors as to the confidential nature of the Confidential Information; and (ii) securing a written acknowledgment and agreement from such Agents, employees and subcontractors that the Confidential Information shall be handled only in accordance with provisions no less restrictive than those contained in this Agreement. This provision shall survive termination of this Agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.