Notice; Defense of Claims An indemnified party may make claims for indemnification hereunder by giving written notice thereof to the indemnifying party within the period in which indemnification claims can be made hereunder. If indemnification is sought for a claim or liability asserted by a third party, the indemnified party shall also give written notice thereof to the indemnifying party promptly after it receives notice of the claim or liability being asserted, but the failure to do so shall not relieve the indemnifying party from any liability except to the extent that it is prejudiced by the failure or delay in giving such notice. Such notice shall summarize the bases for the claim for indemnification and any claim or liability being asserted by a third party. Within 20 days after receiving such notice the indemnifying party shall give written notice to the indemnified party stating whether it disputes the claim for indemnification and whether it will defend against any third party claim or liability at its own cost and expense. If the indemnifying party fails to give notice that it disputes an indemnification claim within 20 days after receipt of notice thereof, it shall be deemed to have accepted and agreed to the claim, which shall become immediately due and payable. The indemnifying party shall be entitled to direct the defense against a third party claim or liability with counsel selected by it (subject to the consent of the indemnified party, which consent shall not be unreasonably withheld) as long as the indemnifying party is conducting a good faith and diligent defense. The indemnified party shall at all times have the right to fully participate in the defense of a third party claim or liability at its own expense directly or through counsel; provided, however, that if the named parties to the action or proceeding include both the indemnifying party and the indemnified party and the indemnified party is advised that representation of both parties by the same counsel would be inappropriate under applicable standards of professional conduct, the indemnified party may engage separate counsel at the expense of the indemnifying party. If no such notice of intent to dispute and defend a third party claim or liability is given by the indemnifying party, or if such good faith and diligent defense is not being or ceases to be conducted by the indemnifying party, the indemnified party shall have the right, at the expense of the indemnifying party, to undertake the defense of such claim or liability (with counsel selected by the indemnified party), and to compromise or settle it, exercising reasonable business judgment. If the third party claim or liability is one that by its nature cannot be defended solely by the indemnifying party, then the indemnified party shall make available such information and assistance as the indemnifying party may reasonably request and shall cooperate with the indemnifying party in such defense, at the expense of the indemnifying party.
Objections to Claims At the time of delivery of any Officer's -------------------- Certificate to the Escrow Agent, a duplicate copy of such certificate shall be delivered to the Shareholder Representative and for a period of thirty (30) days after such delivery, the Escrow Agent shall make no delivery to Parent of any Escrow Amounts pursuant to Section 7.2(d) hereof unless the Escrow Agent shall have received written authorization from the Shareholder Representative to make such delivery. After the expiration of such thirty (30) day period, the Escrow Agent shall make delivery of the Escrow Amount from the Escrow Fund in accordance with Section 7.2(d) hereof, provided that no such payment or delivery may be made if the Shareholder Representative shall object in a written statement to the claim made in the Officer's Certificate, and such statement shall have been delivered to the Escrow Agent prior to the expiration of such thirty (30) day period.
Notice to Class Members 8.4.1 No later than three (3) business days after receipt of the Class Data, the Administrator shall notify Class Counsel that the list has been received and state the number of Class Members, PAGA Members, Workweeks, and Pay Periods in the Class Data.
Indemnification for Certain Claims The Party providing services hereunder, its affiliates and its parent company, shall be indemnified, defended and held harmless by the Party receiving services hereunder against any claim, loss or damage arising from the receiving company’s use of the services provided under this Agreement pertaining to (1) claims for libel, slander or invasion of privacy arising from the content of the receiving company’s own communications, or (2) any claim, loss or damage claimed by the End User of the Party receiving services arising from such company’s use or reliance on the providing company’s services, actions, duties, or obligations arising out of this Agreement.
CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.
Notice of Litigation, Right to Prosecute, Etc No Fund shall be liable for indemnification under this Section 5.03 unless a Person shall have promptly notified such Fund in writing of the commencement of any litigation or proceeding brought against such Person in respect of which indemnity may be sought under this Section 5.03. With respect to claims in such litigation or proceedings for which indemnity by a Fund may be sought and subject to applicable law and the ruling of any court of competent jurisdiction, such Fund shall be entitled to participate in any such litigation or proceeding and, after written notice from such Fund to any Person, such Fund may assume the defense of such litigation or proceeding with counsel of its choice at its own expense in respect of that portion of the litigation for which such Fund may be subject to an indemnification obligation; provided however, a Person shall be entitled to participate in (but not control) at its own cost and expense, the defense of any such litigation or proceeding if such Fund has not acknowledged in writing its obligation to indemnify the Person with respect to such litigation or proceeding. If such Fund is not permitted to participate or control such litigation or proceeding under applicable law or by a ruling of a court of competent jurisdiction, such Person shall reasonably prosecute such litigation or proceeding. A Person shall not consent to the entry of any judgment or enter into any settlement in any such litigation or proceeding without providing each applicable Fund with adequate notice of any such settlement or judgment, and without each such Fund's prior written consent. All Persons shall submit written evidence to each applicable Fund with respect to any cost or expense for which they are seeking indemnification in such form and detail as such Fund may reasonably request.
Breach of Contract Claims To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.
Direct Claim Procedures In the event an Indemnified Party has a claim for indemnity under Section 7.02 against the Indemnifying Party that does not involve a Third Party Claim, the Indemnified Party agrees to give notice in writing of such claim to the Indemnifying Party. Such notice shall set forth in reasonable detail such claim and the basis for indemnification (taking into account the information then available to the Indemnified Party). The failure to so notify the Indemnifying Party shall not relieve the Indemnifying Party of its obligations hereunder, except to the extent such failure shall have actually materially and adversely prejudiced the Indemnifying Party. If the Indemnifying Party does not notify the Indemnified Party within thirty (30) days following the receipt of a notice with respect to any such claim that the Indemnifying Party disputes its indemnity obligation to the Indemnified Party for any Losses with respect to such claim, such Losses shall be conclusively deemed a liability of the Indemnifying Party and the Indemnifying Party shall promptly pay to the Indemnified Party any and all Losses arising out of such claim. If the Indemnifying Party has timely disputed its indemnity obligation for any Losses with respect to such claim, the parties shall proceed in good faith to negotiate a resolution of such dispute and, if not resolved through such negotiations, such dispute shall be resolved by arbitration determined pursuant to Section 9.06.
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Third Party Claim Procedures (a) The Indemnified Party seeking indemnification under Section 7.02 agrees to give reasonably prompt notice in writing to Indemnifying Party of the assertion of any claim or the commencement of any suit, action or proceeding by any third party (“Third Party Claim”) in respect of which indemnity may be sought under Section 7.02. Such notice shall set forth in reasonable detail such Third Party Claim and the basis for indemnification (taking into account the information then available to the Indemnified Party). The failure to so notify the Indemnifying Party shall not relieve the Indemnifying Party of its obligations hereunder, except to the extent such failure shall have actually materially and adversely prejudiced the Indemnifying Party.
