Removal of Tenant Work Sample Clauses

Removal of Tenant Work. Portions of the Tenant Work, as reasonably determined by Landlord to be specialized Tenant Work (e.g. floor and ceiling mounted auxiliary air conditioning units, non-building standard fire suppression/control systems, computer rooms, auditoriums, laboratories, Cabling shall, at the election of Landlord made at the time of Landlord’s approval of the Construction Drawings and Specifications or Change Order, as applicable, either be removed by Tenant at its expense before the expiration of the Term or shall remain upon the Premises and be surrendered therewith at the Expiration Date or earlier termination of this Lease as the property of Landlord without disturbance, molestation or injury. If Landlord requires the removal of all or part of such Tenant Work, Tenant, at its expense, shall repair any damage to the Premises or the Building caused by such removal and restore the Premises to its condition prior to the installation of the Tenant Work. If Tenant fails to remove the Tenant Work upon Landlord’s request, then Landlord may (but shall not be obligated to) remove the same and the cost of such removal, repair and restoration, together with any and all damages which Landlord may suffer and sustain by reason of the failure of Tenant to remove the same, shall be charged to Tenant and paid upon demand. All Cabling installed by Tenant inside any of the interior walls of the Premises, above the ceiling of the Premises, in any portion of the ceiling plenum above or below the Premises, or in any portion of the Common Areas of the Building, including but not limited to any of the shafts or utility rooms of the Building, shall be clearly labeled or otherwise identified as having been installed by Tenant. All Cabling installed by Tenant shall comply with the requirements of the National Electric Code and any other applicable fire and safety codes. Upon the expiration or earlier termination of this Lease, Tenant shall remove all Cabling installed by Tenant anywhere in the Premises or the Building to the point of the origin of such Cabling, and repair any damage to the Premises or the Building resulting from such removal.
Sample 1
AutoNDA by SimpleDocs

Related to Removal of Tenant Work

  • Removal of Tenant’s Property Upon the expiration or earlier termination of this Lease or the termination of Tenant's right of possession of the Premises only, Tenant shall have the right, at its sole cost and expense, for a period of fifteen ( 15) days thereafter to remove Tenant's Property, Distinctive Property and the Financed Personalty, respectively, from the Premises, provided that Tenant shall pay to Landlord Rent due under Article 3 hereof for the actual number of days which elapse during such fifteen (15) day period until the Tenant's Property, Distinctive Property and the Financed Personalty, as applicable, are removed from the Premises. If and to the extent that Tenant fails to remove any of such property by the expiration of said fifteen (15) day period, Landlord agrees that Tenant Lender, TE Lender and Franchisor each shall have the right for a period of forty (45) days thereafter to remove the same from the Premises, provided that Tenant shall pay to Landlord Rent due hereunder for the actual number of days which elapse until Tenant Lender, TE Lender or Franchisor remove the same from the Premises during such forty five (45) day period. If and to the extent that any such property remains on the Premises on the sixtieth (60th) day after such termination, the same shall be deemed abandoned, and at Landlord's option shall become the property of Landlord and may be sold or disposed of as Land-lord may determine; provided, however, that Landlord shall not use, suffer or permit the use of any Distinctive Property unless the attributes or features thereof associated with Tenant or Franchisor are removed or obliterated. Any and all damage to the Building caused by or resulting from the removal of Tenant's Property, Distinctive Property or Financed Personalty shall promptly be repaired at no cost or expense to Landlord and Tenant shall be liable for such cost and expense unless such repairs are made by Tenant, Franchisor or TE Lender, as the case may be.

  • Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.

  • Removal of Improvements Except as otherwise expressly agreed to by Lessor and Lessee, Lessee shall have the right to remove all Tank Farm Assets and other improvements, fixtures, equipment, materials, supplies and personal property installed by Lessee from the Premises upon the termination or expiration of this Lease, but in no event later than the date that is 120 days following the expiration or termination of this Lease (the “Removal Date”) and Lessor shall provide Lessee with access to the Premises at reasonable times until expiration of the Removal Date for the purpose of removing such items. Lessee shall provide Lessor with written notice of its election to remove the Tank Farm Assets and other improvements, fixtures, equipment, materials, supplies and personal property from the Premises at least 60 days prior to the expiration of the Lease. If Lessee elects to remove the Tank Farm Assets and Improvements from the Premises after such removal Lessee shall restore any damage to the Premises and clean the Premises so as to eliminate therefrom any accumulation (other than any de minimis and non-hazardous accumulation) of foreign substances, materials, or debris, in addition to any Environmental Cleanup that may be required under Article 10. Lessee shall pay Lessor pro rata Rent (based on the amount of Rent applicable during the last month prior to the termination or expiration) through the date of Lessee’s complete removal of all such items. During the period of such removal and clean-up, all terms and conditions of this Lease, including, the indemnity and insurance provisions shall continue in full force and effect. If Lessee elects not to remove all of the Tank Farm Assets and Improvements from the Premises on or before the Removal Date, and provided that such facilities are in good working condition at the expiration of the Term (ordinary wear and tear excepted) then, such Tank Farm Assets and Improvements shall be deemed permanently abandoned to Lessor’s sole ownership, and Lessor may remove and dispose of such facilities in any manner which Lessor may deem appropriate, without any liability whatsoever to Lessee. If Lessee elects not to remove all of the Tank Farm Assets and Improvements from the Premises on or before the Removal Date and such facilities are not in good working condition at the expiration of the term (ordinary wear and tear excepted), or Lessee fails to so remove any or all of the Tank Farm Assets and Improvements from the Premises before the Removal Date, then, in addition to all rights and remedies available at law or in equity, without any prior notice, Lessor may (but shall be under no obligation), at Lessor’s option, deem such Tank Farm Assets and Improvements to be permanently abandoned to Lessor’s sole ownership, and Lessor may remove and dispose of such facilities in any manner which Lessor may deem appropriate, without any liability whatsoever to Lessee, and Lessee shall reimburse Lessor for all costs of such removal and disposal upon demand from Lessor. If requested by Lessor, Lessee shall execute any and all documents necessary to evidence that title to the Tank Farm Assets and Improvements that Lessee does not remove by the Removal Date is in Lessor and to extinguish and remove any cloud or potential cloud on the title to the Premises and/or such facilities created by Lessee.

  • Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.

  • Cost of Tenant Improvements Unless specified otherwise herein, Landlord shall bear and pay the cost of the Tenant Improvements (which cost shall include, without limitation, the costs of construction, the cost of permits and permit expediting, the costs of code compliance work, if such work is required as a result of, or is a condition imposed by appropriate governmental authorities for, construction of the Tenant Improvements, and all architectural and engineering services obtained by Landlord in connection with the Tenant Improvements, the Contractor's fees, Landlord's fee for construction administration in an amount which shall not exceed three percent (3%) of hard costs, utilities, and Landlord's Insurance Costs (including, without limitation, course of construction insurance), from the date of this Work Letter until the Lease Commencement Date up to a maximum of $450,000.00 (the "Tenant Improvement Allowance"). The Tenant Improvement Allowance shall be utilized only for building improvements to the Building, and not for signage, furniture costs, any third party consulting or contracting fees, any telecom/cabling costs, or any other purpose. Tenant shall bear and pay the cost of the Tenant Improvements (including but not limited to all of the foregoing fees and costs) in excess of the Tenant Improvement Allowance, if any. The cost of the Tenant Improvements shall exclude the cost of furniture, fixtures and inventory and other items of Tenant's Work (as defined below). Tenant shall have the right to elect to increase the Tenant Improvement Allowance by up to an additional $450,000.00 (the "Additional Allowance"), subject to the following terms and conditions: (i) Tenant shall make such election, if at all, no later than August 15, 1998; (ii) such amount shall be paid to Landlord in equal monthly installments over the seven (7) year Lease Term with interest at 10%, as additional Base Monthly Rent in the manner specified by Article 3 of the Lease; and (iii) the Additional Allowance shall otherwise constitute a part of the Tenant Improvement Allowance and shall be subject to the restrictions and conditions on such Tenant Improvement Allowance provided in this Work Letter. Notwithstanding anything to the contrary contained herein or in the Lease, Landlord shall be responsible at its sole cost and expense for the incremental costs incurred by either Landlord or Tenant for asbestos removal within the interior of the Leased Premises required solely as a result of the construction of the Tenant Improvements. 5.

  • Construction of Tenant Improvements by Tenants Agents Construction Contract; Cost Budget. Prior to Tenant's execution of ---------------------------------- the construction contract and general conditions with Contractor (the "Contract"), Tenant shall submit the Contract to Landlord for its approval, which approval shall not be unreasonably withheld or delayed. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, of the final costs to be incurred, or which have been incurred, as set forth more particularly in Sections 2.2.1.1 through ---------------- 2.2.1.8 above, in connection with the design and construction of the Tenant ------- Improvements to be performed by or at the direction of Tenant or the Contractor (which costs form a basis for the amount of the Contract, if any (the "Final Costs"). Prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with a completion bond in an amount equal to the Final Costs to ensure Landlord of the completion of the Tenant Improvements.

  • Removal of Alterations If Tenant fails to remove by the expiration or earlier termination of this Lease all of its personal property, or any Alterations identified by Landlord for removal, Landlord may, at its option, treat such failure as a hold-over pursuant to Subparagraph 11(b) above, and/or Landlord may (without liability to Tenant for loss thereof) treat such personal property and/or Alterations as abandoned and, at Tenant's sole cost and expense, and in addition to Landlord's other rights and remedies under this Lease, at law or in equity: (a) remove and store such items; and/or (b) upon ten (10) days prior notice to Tenant, sell, discard or otherwise dispose of all or any such items at private or public sale for such price as Landlord may obtain or by other commercially reasonable means. Tenant shall be liable for all costs of disposition of Tenant's abandoned property and Landlord shall have no liability to Tenant with respect to any such abandoned property. Landlord agrees to apply the proceeds of any sale of any such property to any amounts due to Landlord under this Lease from Tenant (including Landlord's attorneys' fees and other costs incurred in the removal, storage and/or sale of such items), with any remainder to be paid to Tenant.

  • Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.

  • Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.

  • Restoration of Tenant's Property If Tenant is required to restore any Property as hereinabove provided, Tenant shall either (a) restore all alterations and improvements made by Tenant and Tenant’s Personal Property, or (b) replace such alterations and improvements and Tenant’s Personal Property with improvements or items of the same or better quality and utility in the operation of such Property.

Time is Money Join Law Insider Premium to draft better contracts faster.