Specific Enforcement Each party hereto acknowledges that the remedies at law of the other parties for a breach or threatened breach of this Agreement would be inadequate and, in recognition of this fact, any party to this Agreement, without posting any bond, and in addition to all other remedies that may be available, shall be entitled to obtain equitable relief in the form of specific performance, a temporary restraining order, a temporary or permanent injunction or any other equitable remedy that may then be available.
Prevailing Wage The Recipient shall require that all Contractors and subcontractors working on the Project comply with the prevailing wage requirements contained in Revised Code Sections 164.07(B) and 4115.03 through 4115.16;
Prevailing Wages Contractor is aware of the requirements of California Labor Code Section 1720 et seq., and 1770 et seq., as well as California Code of Regulations, Title 8, Section 16000 et seq., (“Prevailing Wage Laws”), which require the payment of prevailing wage rates and the performance of other requirements on “public works” and “maintenance” projects. Since the Services are being performed as part of an applicable “public works” or “maintenance” project, as defined by the Prevailing Wage Laws, and since the total compensation is $1,000 or more, Contractor agrees to fully comply with such Prevailing Wage Laws. District shall provide Contractor with a copy of the prevailing rates of per diem wages in effect at the commencement of this Contract. Contractor shall make copies of the prevailing rates of per diem wages for each craft, classification or type of worker needed to execute the Services available to interested parties upon request, and shall post copies at Contractor’s principal place of business and at the project site. Contractor shall defend, indemnify and hold the District, its officials, officers, employees and agents free and harmless from any claim or liability arising out of any failure or alleged failure to comply with the Prevailing Wage Laws. Contractor and any subcontractor shall forfeit a penalty of up to $200 per calendar day or portion thereof for each worker paid less than the prevailing wage rates.
Contract Enforcement Note: NO EXCEPTIONS OR REVISIONS WILL BE CONSIDERED TO A, B2, 5-7. Enforcement of Contract and Dispute Resolution Note: NO EXCEPTIONS OR REVISIONS WILL BE CONSIDERED
Interpretation and Enforcement 1. The Parties shall take all appropriate measures, whether general or specific, to ensure fulfilment of the obligations arising out of this Agreement and shall refrain from any measures which would jeopardise attainment of the objectives of this Agreement.
Law Enforcement 24.1 Each Party may cooperate with law enforcement authorities and national security authorities to the full extent required or permitted by Applicable Law in matters related to Services provided by it under this Agreement, including, but not limited to, the production of records, the establishment of new lines or the installation of new services on an existing line in order to support law enforcement and/or national security operations, and, the installation of wiretaps, trap-and-trace facilities and equipment, and dialed number recording facilities and equipment.
AND ENFORCEMENT 59. If at any time the City desires to modify any portion of this Agreement because of changed conditions making performance impossible or impractical or for any other reason, it will promptly notify the Department in writing, setting forth the facts and circumstances thought to justify modification and the substance of the proposed modification. Until there is written Agreement by the Department to the proposed modification, the proposed modification will not take effect. These actions must receive the prior written approval of the Department, which approval will not be unreasonably withheld or delayed.
JOB NOTIFICATION AND ENFORCEMENT 4.1 The Employer shall forward a job notification to the appropriate International Union Representative designated by the Union for the area involved and a copy for the Local Union(s) having territorial jurisdiction, immediately upon his knowledge of all work to be done by the Employer and all subcontractors under the terms and conditions of this Agreement. The Union will designate the Local Union(s) which will have territorial jurisdiction. The job notification form to be used is attached to this Agreement as Addendum A.
Construction and Enforcement This Agreement shall be construed in accordance with the laws of the State of Florida, without and application of the principles of conflicts of laws. If it becomes necessary for any party to institute legal action to enforce the terms and conditions of this Agreement, and such legal action results in a final judgment in favor of such party ("Prevailing Party"), then the party or parties against whom said final judgment is obtained shall reimburse the Prevailing Party for all direct, indirect or incidental expenses incurred, including, but not limited to, all attorney's fees, court costs and other expenses incurred throughout all negotiations, trials or appeals undertaken in order to enforce the Prevailing Party's rights hereunder. Any suit, action or proceeding with respect to this Agreement shall be brought in the state or federal courts located in St. Lucie County in the State of Florida. The parties hereto hereby accept the exclusive jurisdiction and venue of those courts for the purpose of any such suit, action or proceeding. The parties hereto hereby irrevocably waive, to the fullest extent permitted by law, any objection that any of them may now or hereafter have to the laying of venue of any suit, action or proceeding arising out of or relating to this Agreement or any judgment entered by any court in respect thereof brought in St. Lucie County, Florida, and hereby further irrevocably waive any claim that any suit, action or proceeding brought in St. Lucie County, Florida, has been brought in an inconvenient forum.
PREVAILING WAGE ACT Without limiting the scope of any other provision of this Agreement, Concessionaire agrees to comply with the New Jersey Prevailing Wage Act, P.L. 1963, Chapter 150as codified in N.J.S.A. 34:11-56.25, et seq. Concessionaire also agrees to comply with 42 U.S.C. § 9604 (g)(1). If any conflict exists between the New Jersey Prevailing Wage Law and § 9604 (g)(1), the Concessionaire must comply with the federal requirements.
