Paragon Initiated Changes Sample Clauses

Paragon Initiated Changes. Before Paragon may amend the Project Plan, Paragon shall prepare a Change Order describing in reasonable detail the nature of such change(s), and propose such Change Order to Client for Client’s review. All approved Change Orders shall be signed by the Project Manager of each Party or by such other authorized representatives of Paragon and Client that the Project Managers may designate. If any changes contemplated by a Change Order will have a financial or other impact on the scope of the Project, Paragon shall provide Client with a written description of such impacts in the Change Order. If Client approves the Change Order notwithstanding Paragon’s notice of any resulting cost increase, Client shall reimburse Paragon for the cost of such changes as detailed in the Change Order. Upon Paragon and Client’s approval of the Change Order, the Change Order will be implemented as soon as it is commercially practical to do so in a good faith effort to meet the development and manufacturing timelines as set forth in the Project Plan.
Sample 1
AutoNDA by SimpleDocs
Paragon Initiated Changes. Before Paragon may amend the SOW or Project Plan, Paragon shall prepare a Change Order describing in reasonable detail the nature of such change(s) and propose such Change Order to Client for Client’s review and written approval. All approved Change Orders shall be signed by the Project Manager of each Party or by such other authorized representatives of Paragon and Client. If any changes contemplated by a Change Order will have a financial or other impact on the scope of the Project, Paragon shall provide Client with a written description of such impacts in the Change Order. If Client approves the Change Order, Client shall reimburse Paragon for the cost of such changes as detailed in the Change Order. Upon Paragon and Client’s approval of the Change Order, the Change Order will be implemented as soon as it is commercially practical to do so in a good faith effort to meet the development and manufacturing timelines as set forth in the SOW/Project Plan.
Sample 1

Related to Paragon Initiated Changes

  • SCOPE CHANGES The Commissioner reserves the right to require, by written order, changes to the scope of the Contract, by altering, adding to or deducting from the Bid Specifications, such changes to be within the general scope of the Contract. If any such change causes an increase or decrease in the cost of, or the time required for, performance of any part of the work under the Contract, whether or not changed by the order, the Commissioner shall, upon notice from Contractor as hereafter stated, make an equitable adjustment in the Contract price, the delivery schedule or both and shall modify the Contract. The Contractor must assert its right to an adjustment under this clause within thirty days from the date of receipt of the written order. However, if the Commissioner decides that the facts justify it, the Commissioner may provide an adjustment without receipt of a proposal. Failure to agree to any adjustment shall be a dispute under the Disputes clause, provided, however, that nothing in this clause shall excuse the Contractor from proceeding with the Contract as changed.

  • Program Changes Contractor agrees to inform the County of any alteration in program or service delivery at least thirty (30) days prior to the implementation of the change, or as soon as reasonably feasible.

  • Product Changes Vocera shall have the right, in its absolute discretion, without liability to End User, to update to provide new functionality or otherwise change the design of any Product or to discontinue the manufacture or sale of any Product. Vocera shall notify End User at least 90 days prior to the delivery of any Product which incorporates a change that adversely affects form, fit or function (“Material Change”). Vocera shall also notify End User at least 90 days prior to the discontinuance of manufacture of any Product. Notification will be made as soon as reasonably practical for changes associated with regulatory or health and safety issues.

  • Contractor Changes The Contractor shall notify DAS in writing no later than ten (10) Days from the effective date of any change in:

  • MINOR CHANGES IN THE WORK 7.4.1 The Architect will have authority to order minor changes in the Work not involving adjustment in the Contract Sum or extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes shall be effected by written order and shall be binding on the Owner and Contractor. The Contractor shall carry out such written orders without delay.

  • Interim Changes Except as set forth on Schedule 3.29, since December 31, 2006, there has been no:

  • CONTRACT ITEM CHANGES A. If a manufacturer discontinues a contracted item, that item will automatically be considered deleted from the contract with no penalty to Contractor. However, H-GAC may at its sole discretion elect to make a contract award to the next lowest Respondent for the item, or take any other action deemed by H-GAC, at its sole discretion, to be in the best interests of its Customers.

  • GSA Changes Where NYS Net Prices are based on an approved GSA Schedule, the date the approved GSA Schedule pricing decreases during the Contract term; or

  • Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Housing.

  • Project Changes 1.8.1. All changes shall be administered per the UGC.

Time is Money Join Law Insider Premium to draft better contracts faster.