Owner’s Right to Reject Sample Clauses

Owner’s Right to Reject. Owner reserves the right to reject a certificate of insurance if CMTISP’s insurance company is widely regarded in the insurance industry as financially unstable. Such determination of instability would include, but not be limited to, insurance companies with less than AVIII rating in the A.M. Best insurance rating guide.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Owner’s Right to Reject. Prior to execution of the GMP, the Owner or Design Professional shall provide written notice of any reasonable objection to any subcontractor or material supplier proposed by the CM/GC. Upon receipt of such notice, the CM/GC may propose a substitute and identify any change in any bid package amount caused by such substitution for negotiation with the Owner.
Sample 1Sample 2
Owner’s Right to Reject. The Owner reserves the right to reject a certificate of insurance if the Architect’s insurance company is widely regarded in the insurance industry as financially unstable. Such determination of instability would include, but not be limited to, insurance companies with less than AVIII rating in the A.M. Best insurance rating guide.
Sample 1Sample 2
Owner’s Right to Reject. BIDS: Owner reserves the right to reject a Bid which is in any way incomplete or irregular or to waive informalities or irregularities in a Bid received, and accept a Bid, which in the Owner’s judgment is in the Owner’s best interests. EXAMINATION OF DOCUMENTS AND SITE:
Sample 1

Related to Owner’s Right to Reject

  • City’s Right to Reject The City reserves the right to reject a certificate of insurance if Contractor’s insurance company is widely regarded in the insurance industry as financially unstable. This would include but is not limited to insurance companies with no less than AVIII rating in the A.M. Best insurance rating guide.

  • Right to Reject Notwithstanding Buyer’s rights pursuant to Sec. 8.5 and save other rights pursuant to this Order, Buyer may reject any goods within 2 months from the delivery if they are materially defective and in Buyer’s reasonable assessment do not allow a commercially reasonable use. In that case, no payments for these goods are due.

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • Owner’s Right to Suspend Work The Owner reserves the right, with or without the concurrence of the Design Professional, to suspend the Work at any time or from time to time at the Owner's sole discretion, upon giving Contractor five days advanced written notice thereof. If the Owner exercises this right and then resumes the Work covered hereby, Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the suspension and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's suspension, to include compensation based upon the rate for Time Dependent Overhead Costs. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • OWNER’S RIGHT TO STOP THE WORK If the Contractor fails to correct Work that is not in accordance with the requirements of the Contract Documents as required by Section 12.2 or repeatedly fails to carry out Work in accordance with the Contract Documents, the Owner may issue a written order to the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, the right of the Owner to stop the Work shall not give rise to a duty on the part of the Owner to exercise this right for the benefit of the Contractor or any other person or entity.

  • OWNER’S RIGHTS B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT.

  • Right to Refuse Employees have the right to refuse to undergo drug and alcohol testing. If an employee refuses to undergo drug or alcohol testing requested or required by the Employer, no such test shall be given.

  • OWNER’S RIGHT TO CLEAN UP If a dispute arises among the Design-Builder, separate contractors and the Owner as to the responsibility under their respective contracts for maintaining the premises and surrounding area free from waste materials and rubbish, the Owner may clean up and will allocate the cost among those responsible.

  • BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.

  • Right to Refuse Work Consistent with M.S. 182.654, Subd. 11, employees have the right to refuse work in certain circumstances as specified in the statute.

Time is Money Join Law Insider Premium to draft better contracts faster.