Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.
Project or Building Name and Signage Landlord shall have the right at any time to change the name of the Project or Building and to install, affix and maintain any and all signs on the exterior and on the interior of the Project or Building as Landlord may, in Landlord’s sole discretion, desire. Tenant shall not use the name of the Project or Building or use pictures or illustrations of the Project or Building in advertising or other publicity or for any purpose other than as the address of the business to be conducted by Tenant in the Premises, without the prior written consent of Landlord.
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 90 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenants’ Work,” and “Force Majeure Delays” shall have the meanings set forth for such terms in the Work Letter. If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 90 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect; provided, however, that if Landlord does not Deliver the Premises within 150 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, in which case subsections (a) and (b) of this paragraph shall apply. If Tenant does not elected to void this Lease within 10 business days of the lapse of such 150 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect.
Acceptance of Leased Premises Tenant acknowledges that: (a) it has been advised by Landlord, Landlord’s Broker and Tenant’s Broker, if any, to satisfy itself with respect to the condition of the Leased Premises (including, without limitation, the HVAC, electrical, plumbing and other mechanical installations, fire sprinkler systems, security, environmental aspects, and compliance with applicable laws, ordinances, rules and regulations) and the present and future suitability of the Leased Premises for Tenant’s intended use; (b) Tenant has made such inspection and investigation as it deems necessary with reference to such matters and assumes all responsibility therefor as the same relate to Xxxxxx’s occupancy of the Leased Premises and the Term of this Lease; and (c) neither Landlord nor Landlord’s Broker nor any of Landlord’s agents has made any oral or written representations or warranties with respect to the condition, suitability or fitness of the Leased Premises other than as may be specifically set forth in this Lease. Tenant accepts the Leased Premises in its AS IS condition existing on the date Tenant executes this Lease, subject to all matters of record and applicable laws, ordinances, rules and regulations. Tenant acknowledges that neither Landlord nor Landlord’s Broker nor any of Landlord’s agents has agreed to undertake any alterations or additions or to perform any maintenance or repair of the Leased Premises except for the routine maintenance and janitorial work specified herein and except as may be expressly set forth in Exhibit B. If Landlord, for any reason whatsoever, cannot deliver possession of the Leased Premises to Tenant on the estimated commencement date in the condition specified in this Section 2.2, Landlord shall neither be subject to any liability nor shall the validity of this Lease be affected; provided, the Term and the obligation to pay Gross Rent shall commence on the date possession is actually tendered to Tenant (which date shall become the Term Commencement Date) and the Term Expiration Date shall be extended commensurately. If the Term Commencement Date and/or the Term Expiration Date is other than the Term Commencement Date and Term Expiration Date specified in the Basic Lease Information or is not set forth in the Basic Lease Information, the parties shall execute that certain Confirmation of Term of Lease, substantially in the form of Exhibit C hereto specifying the actual Term Commencement Date, Term Expiration Date and the date on which Tenant is to commence paying Rent. Tenant shall execute and return such Confirmation of Term of Lease to Landlord within fifteen (15) days after Xxxxxx’s receipt thereof. If Xxxxxx fails to execute and return (or reasonably object in writing to) the Confirmation of Term of Lease within fifteen (15) days after receiving it, Tenant shall be deemed to have executed and returned it without exception.
Landlord's Waivers Any lessor of Tenant's Personal Property may, upon notice to Landlord and during reasonable hours, enter the Property and take possession of any of Tenant's Personal Property without liability for trespass or conversion upon a default by Tenant, provided that such lessor provide Landlord with the opportunity to cure the defaults of Tenant on terms and conditions satisfactory to such lessor and Landlord.
Construction of Lease This Lease has been prepared by Landlord and its professional advisors and reviewed by Tenant and its professional advisors. Landlord, Tenant, and their advisors believe that this Lease is the product of all their efforts, that it expresses their agreement, and agree that it shall not be interpreted in favor of either Landlord or Tenant or against either Landlord or Tenant merely because of their efforts in preparing it.
Completion of Landlord’s Work Landlord shall substantially complete or cause to be substantially completed Landlord’s Work in a good and workmanlike manner, in accordance with the TI Permit subject, in each case, to Minor Variations and normal “punch list” items of a non-material nature that do not interfere with the use of the Premises and shall obtain a certificate or temporary certificate of occupancy (or an equivalent approval) for the Premises permitting lawful occupancy of the Premises during the Term (but specifically excluding any permits, licenses or other governmental approvals required to be obtained in connection with Tenant’s operations in the Premises not relating to Landlord’s Work)(“Substantial Completion” or “Substantially Complete”). Upon Substantial Completion of Landlord’s Work, Landlord shall require the TI Architect and the general contractor to execute and deliver, for the benefit of Tenant and Landlord, a Certificate of Substantial Completion in the form of the American Institute of Architects (“AIA”) document G704. For purposes of this Work Letter, “Minor Variations” shall mean any modifications reasonably required: (i) to comply with all applicable Legal Requirements and/or to obtain or to comply with any required permit (including the TI Permit); (ii) to comply with any request by Tenant for modifications to Landlord’s Work; (iii) to comport with good design, engineering, and construction practices that are not material; or (iv) to make reasonable adjustments in accordance with good design, engineering, and construction practices for field deviations or conditions encountered during the construction of Landlord’s Work.
Occupancy and Use Except for (i) the period of time permitted by this Lease for Tenant to perform Tenant's Work to prepare the Premises for Tenant's initial occupancy as set forth in Section 3.2.1 and (ii) a period of six (6) months at the end of the Term, and (iii) temporary vacancies of not more than forty percent (40%) of the Premises at any one time, continuously from the Commencement Date, to use and occupy the Premises only for the Permitted Uses, and from time to time, to procure all licenses and permits necessary therefor at Tenant's sole expense, and to the extent set forth in Section 10.21 hereof, with Landlord's cooperation. Without limitation, Tenant shall comply in all material respects with all federal, state, and municipal laws, ordinances, and regulations governing, and all Development Approvals, Subsequent Approvals and Title Exceptions applicable to, Tenant's particular use or manner of use of the Premises. Tenant shall be solely responsible for procuring and complying at all times with any and all necessary permits directly relating or incident to: the conduct of its office activities on the Premises; its, transportation, storage, handling, use and disposal of any chemical or radioactive or bacteriological or pathological substances or organisms or other hazardous wastes or environmentally dangerous substances or materials or medical waste. Within thirty (30) days of a request by Landlord, which request shall be made not more than once during each period of twelve (12) consecutive months during the Term hereof, unless otherwise requested by any mortgagee of Landlord, Tenant shall furnish Landlord with copies of all such permits which Tenant possesses or has obtained together with a certificate certifying that such permits are all of the permits which Tenant possesses or has obtained with respect to the Premises. Tenant shall be entitled to redact any Confidential Information from the copies of such permits and accompanying certificates of Tenant. Tenant shall promptly give notice to Landlord of any warnings or violations relative to the matters described in this Section 5.1.2 received from any federal, state, or municipal agency or by any court of law and shall promptly cure the conditions causing any such violations. Tenant shall not be deemed to be in default of its obligations under the preceding sentence to promptly cure any condition causing any such violation in the event that, in lieu of such cure, Tenant shall contest the validity of such violation by appellate or other proceedings permitted under applicable law, provided that: (i) any such contest is made reasonably and in good faith, (ii) Tenant makes provisions, including, without limitation, posting bond(s) or giving other security, acceptable to Landlord to protect Landlord, the Building, the Lot and the Complex from any liability, costs, damages or expenses arising in connection with such violation and failure to cure, (iii) Tenant shall agree to indemnify, defend (with counsel reasonably acceptable to Landlord) and hold Landlord harmless from and against any and all liability, costs, damages, or expenses arising in connection with such condition and/or violation, (iv) Tenant shall promptly cure any violation in the event that its appeal of such violation is overruled or rejected, and (v) Tenant shall certify to Landlord's satisfaction that Tenant's decision to delay such cure shall not result in any actual or threatened bodily injury or property damage to Landlord, any tenant or occupant of the Building, the Lot or the Complex, or any other person or entity. Landlord agrees that any Confidential Information gained or obtained by Landlord pursuant to this Section 5.1.2 shall be kept confidential in accordance with Section 10.15 hereof.
Inspection of Agreement A copy of this Agreement shall be available at all reasonable times at the principal corporate trust office of the Warrant Agent for inspection by the holder of any Warrant Certificate. The Warrant Agent may require such holder to submit his Warrant Certificate for inspection by it.
