Notice of Developments Each Party will give prompt written notice to the other Party of any material adverse development causing a breach of any of its own representations and warranties in Section 3 and Section 4 above. No disclosure by any Party pursuant to this Section 5(f), however, shall be deemed to amend or supplement the Disclosure Schedule or to prevent or cure any misrepresentation, breach of warranty, or breach of covenant.
NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.
Notice of Delay 12.1. When anything delays or threatens to delay the timely performance of the Purchase Order, Supplier must immediately provide written notice to Buyer in writing of all relevant information, including but not limited to the reasons for the potential delay and Supplier’s short-term and long-term mitigation actions.
Notice of Defects If, based on Consulting Engineer/Architect's involvement during the construction phase, Consulting Engineer/Architect observes or otherwise becomes aware of any defect in the work, he shall give prompt written notice to City of such defects and their approximate location on the Project. However, Consulting Engineer/Architect shall not have control over or charge of and shall not be responsible for construction means, methods, techniques, sequences or procedures, or for safety precautions, inspections and programs in connection with the work, since these are solely the Contractor's responsibility under the contract for construction. Consulting Engineer/Architect shall not be responsible for the Contractor's schedules or failure to carry out the work in accordance with the Contract Documents. Consulting Engineer/Architect shall not have control over or charge of acts or omissions of the Contractor, Contractor's subcontractors, or their agents or employees.
Notice of Decision The Plan Administrator shall notify the claimant in writing of its decision on review. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth:
Notice of Events As soon as Guarantor obtains knowledge thereof, Guarantor shall give Guarantied Party written notice of any condition or event which has resulted in (a) a material adverse change in the financial condition of Guarantor or Company or (b) any Event of Default or Potential Event of Default.
Notice of Complaints Each Purchaser shall promptly notify the applicable Seller upon becoming aware of any complaint concerning any Serviced Appointment made by any party to the Serviced Corporate Trust Contract, any Securityholder, any Credit Enhancement Provider or any rating agency.
Notice of Defaults If a Default or Event of Default occurs and is continuing and if it is known to the Trustee, the Trustee shall mail to Holders of Notes a notice of the Default or Event of Default within 90 days after it occurs. Except in the case of a Default or Event of Default in payment of principal of, premium, if any, or interest on any Note, the Trustee may withhold the notice if and so long as a committee of its Responsible Officers in good faith determines that withholding the notice is in the interests of the Holders of the Notes.
Notice of Impositions Lessor shall give prompt Notice to Lessee of all Impositions payable by Lessee hereunder of which Lessor at any time has knowledge, provided that Lessor’s failure to give any such Notice shall in no way diminish Lessee’s obligations hereunder to pay such Impositions, but such failure shall obviate any default hereunder for a reasonable time after Lessee receives Notice of any Imposition which it is obligated to pay during the first taxing period applicable thereto.
Notice of Completion The Interconnection Customer shall notify the Transmission Provider and the Interconnected Transmission Owner in writing when it has completed construction of (i) the Customer Facility;
