Material Occurrences Promptly notify Agent in writing upon the occurrence of (a) any Event of Default or Default; (b) any event, development or circumstance whereby any financial statements or other reports furnished to Agent fail in any material respect to present fairly, in accordance with GAAP consistently applied, the financial condition or operating results of any Borrower as of the date of such statements; (c) any accumulated retirement plan funding deficiency which, if such deficiency continued for two plan years and was not corrected as provided in Section 4971 of the Code, could subject any Borrower to a tax imposed by Section 4971 of the Code; (d) each and every default by any Borrower which might result in the acceleration of the maturity of any Indebtedness, including the names and addresses of the holders of such Indebtedness with respect to which there is a default existing or with respect to which the maturity has been or could be accelerated, and the amount of such Indebtedness; and (e) any other development in the business or affairs of any Borrower which could reasonably be expected to have a Material Adverse Effect; in each case describing the nature thereof and the action Borrowers propose to take with respect thereto.
Reports of unusual occurrence The Contractor shall, during the Maintenance Period, prior to the close of each day, send to the Authority and the Authority’s Engineer, by facsimile or e- mail, a report stating accidents and unusual occurrences on the Project Highway relating to the safety and security of the Users and Project Highway. A monthly summary of such reports shall also be sent within 3 (three) business days of the closing of month. For the purposes of this Clause 15.4, accidents and unusual occurrences on the Project Highway shall include:
Name Collision Occurrence Assessment 6.2.1 Registry Operator shall not activate any names in the DNS zone for the Registry TLD except in compliance with a Name Collision Occurrence Assessment provided by ICANN regarding the Registry TLD. Registry Operator will either (A) implement the mitigation measures described in its Name Collision Occurrence Assessment before activating any second-‐level domain name, or (B) block those second-‐level domain names for which the mitigation measures as described in the Name Collision Occurrence Assessment have not been implemented and proceed with activating names that are not listed in the Assessment.
Accidents and Dangerous Occurrences The Hirer must report all accidents involving injury to the public to a member of the Village Hall management committee as soon as possible and complete the relevant section in the Village Hall’s accident book. Any failure of equipment belonging to the Village Hall or brought in by the Hirer must also be reported as soon as possible. Certain types of accident or injury must be reported on a special form to the local authority. The Hall Secretary will give assistance in completing this form. This is in accordance with the Reporting of Injuries, Diseases and Dangerous Occurrences Regulations 1995 (RIDDOR).
Name Collision Occurrence Management 6.1. No-‐Activation Period. Registry Operator shall not activate any names in the DNS zone for the Registry TLD (except for "NIC") until at least 120 calendar days after the effective date of this agreement. Registry Operator may allocate names (subject to subsection 6.2 below) during this period only if Registry Operator causes registrants to be clearly informed of the inability to activate names until the No-‐Activation Period ends.
Re-export and Serious Shortage Where compliance with the provisions of Articles 6 and 7 leads to:
Regulatory Approvals; No Defaults (a) No consents or approvals of, or waivers by, or filings or registrations with, any Governmental Authority are required to be made or obtained by HCBF or any of its Subsidiaries in connection with the execution, delivery or performance by HCBF of this Agreement or to consummate the transactions contemplated by this Agreement, except as may be required for (i) filings of applications and notices with, and receipt of consents, authorizations, approvals, exemptions or nonobjections from, the SEC, NASDAQ, state securities authorities, the Financial Industry Regulatory Authority, Inc., applicable securities, commodities and futures exchanges, and other industry self-regulatory organizations (each, an “SRO”), (ii) filings of applications or notices with, and consents, approvals or waivers by the FRB, the FDIC and applicable state banking agencies, the Office of the Comptroller of the Currency (the “OCC”), the Florida Office of Financial Regulation (the “FOFR”) and other banking, regulatory, self-regulatory or enforcement authorities or any courts, administrative agencies or commissions or other Governmental Authorities and approval of or non-objection to such applications, filings and notices (taken together with the items listed in clause (i), the “Regulatory Approvals”), (iii) the filing with the SEC of the Proxy Statement-Prospectus and the Registration Statement and declaration of effectiveness of the Registration Statement, (iv) the filing of the Articles of Merger and the filing of documents with the OCC, applicable Governmental Authorities, and the Secretary of State of the State of Florida to cause the Bank Merger to become effective and (v) such filings and approvals as are required to be made or obtained under the securities or “Blue Sky” laws of various states in connection with the issuance of the shares of CenterState Common Stock pursuant to this Agreement and approval of listing of such CenterState Common Stock on the NASDAQ. Subject to the receipt of the approvals referred to in the preceding sentence and the Requisite HCBF Shareholder Approval, the execution, delivery and performance of this Agreement and the consummation of the transactions contemplated hereby by HCBF do not and will not (1) constitute a breach or violation of, or a default under, the articles of incorporation, bylaws or similar governing documents of HCBF or any of its respective Subsidiaries, (2) violate any statute, code, ordinance, rule, regulation, judgment, order, writ, decree or injunction applicable to HCBF or any of its Subsidiaries, or any of their respective properties or assets, (3) conflict with, result in a breach or violation of any provision of, or the loss of any benefit under, or a default (or an event which, with or without notice or lapse of time, or both, would constitute a default) under, result in the creation of any Lien under, result in a right of termination or the acceleration of any right or obligation under any permit, license, credit agreement, indenture, loan, note, bond, mortgage, reciprocal easement agreement, lease, instrument, concession, contract, franchise, agreement or other instrument or obligation of HCBF or any of its Subsidiaries or to which HCBF or any of its Subsidiaries, or their respective properties or assets is subject or bound, or (4) require the consent or approval of any third party or Governmental Authority under any such Law, rule or regulation or any judgment, decree, order, permit, license, credit agreement, indenture, loan, note, bond, mortgage, reciprocal easement agreement, lease, instrument, concession, contract, franchise, agreement or other instrument or obligation.
No Material Adverse Change in Financial Statements All consolidated and consolidating financial statements related to Borrower and any Subsidiary that are delivered by Borrower to Bank fairly present in all material respects Borrower’s consolidated and consolidating financial condition as of the date thereof and Borrower’s consolidated and consolidating results of operations for the period then ended. There has not been a material adverse change in the consolidated or in the consolidating financial condition of Borrower since the date of the most recent of such financial statements submitted to Bank.
Tenant Delay If substantial completion of the Tenant Improvements, Warm Shell Improvements or Base Building is delayed due to any of the following (collectively, "Tenant Delays"), then the Delivery Date and/or Commencement Date, as applicable, shall be adjusted to reflect what the substantial completion date would have been if there had been no delay: (i) Tenant's failure to timely submit any items required by this Work Letter, including, without limitation, Tenant's Plans; (ii) Tenant Modifications; (iii) Tenant's failure to comply with Landlord's contractor's schedule; (iv) Tenant's or Tenant's Contractor's failure to comply with Paragraph 8, (v) Tenant's requested changes to the Tenant's Plans after they are approved by Landlord; (vi) Tenant's request for materials, finishes or installations which require longer than thirty (30) days to complete; (vii) delays caused by Tenant in construction of the Warm Shell Improvements or the Tenant Improvements; or (viii) any other event expressly constituting "Tenant Delay" pursuant to any provision of this Work Letter. Landlord shall give Tenant at least five (5) days prior notice if Landlord becomes aware that Tenant is in danger of causing a Tenant Delay, and if Tenant takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Delivery Date or Commencement Date shall be made on account of such Tenant Delay; provided, however, that if such delay was not reasonably foreseeable by Landlord, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Landlord becomes aware of such delay or potential delay; and provided further, that no such notice shall be required if Tenant Delay results from Tenant's failure to perform any obligation within a specific date or time period (including, without limitation, any delay in delivery of Tenant's space plan or Working Drawings or non-compliance with Landlord's contractor's schedule), or from schedule changes resulting from Tenant Modifications of which Tenant is advised by Landlord's architect or contractor as provided in Paragraph 4, or from causes that, due to the parties' relative positions with respect to the construction process, are more likely to be foreseeable by Tenant than by Landlord.
Move-in; Inspection; Delay Before Resident may access or occupy the premises, any required installments or other payments then due (including any Administrative Fee, which is earned and payable upon mutual execution of this Agreement) must be paid in full with cleared funds and guaranty or prepayment requirements satisfied. The application fee (if any) is non-refundable and is not applicable toward any other payments required of Resident under this Agreement. Prior to Resident’s taking possession of the assigned bedroom space (and any re-assigned bedroom space), Resident will conduct an inspection of the assigned bedroom space and apartment and will note on the Check-In/Check-Out Inspection Report (“Inspection Report”) any defects, damage or other conditions observed, if not already identified by Owner on such report; upon completion and approval by Owner, the Inspection Report will become part of this Agreement. At the time of move-out, Resident is encouraged to inspect the bedroom space and apartment with Owner’s representative by making an appointment during business hours at least 48 hours in advance. Within three business days following Resident’s move-out (or, as applicable, following the move-out of all residents of an apartment) at the termination of this Agreement, or within a reasonable time if Resident moves out without notifying Owner, Owner will note the then-present condition of the assigned bedroom space and apartment, including all appliances and fixtures, and any damages incurred and/or extraordinary cleaning deemed necessary by Owner or extraordinary wear as determined by Owner. Resident will promptly pay all costs of restoring the bedroom space and apartment to the same condition upon move-in, less normal wear. Resident acknowledges that except as provided in the Inspection Report, each bedroom space and apartment are being delivered in "as-is" condition, and Resident’s acceptance of the assigned bedroom space and apartment at the beginning of the Term constitutes Resident’s acknowledgment that the bedroom space and apartment and all fixtures are in good repair and condition. Owner will not be responsible for any damages or consequences suffered by Resident as a result of Owner’s inability to timely deliver possession of the apartment or assigned bedroom space to Resident on the anticipated Start Date; in such event, the rent payable will be abated until Owner tenders possession and such delay will not extend or decrease the term or change the End Date. Resident acknowledges that any model apartment at the Property shown to Resident in person, online or through other means is intended to be representative of the general quality and type of construction and materials within apartments. Specific items of décor and furnishings and the actual colors, styles, materials, upholstery and other treatments in the apartment assigned to Resident may vary from those in the model apartment. The actual apartment assigned to Resident may also vary in approximate size, square footage and layout. Resident’s apartment will not include custom lighting, lamps, decorations, linens, unattached appliances or other personal property as may be shown in the model apartment.
