Late Notice Actual Costs Claim Process Sample Clauses

Late Notice Actual Costs Claim Process. Within 56 days (or such other period as the parties may agree) of receipt by Network Rail of a Late Notice Actual Costs Claim Notice, Network Rail shall notify the Train Operator that either:
Sample 1Sample 2Sample 3See All (22)
AutoNDA by SimpleDocs
Late Notice Actual Costs Claim Process. Within 56 days (or such other period as the parties may agree) of receipt by the CVL IM of a Late Notice Actual Costs Claim Notice, the CVL IM shall notify the Train Operator that either:
Sample 1Sample 2Sample 3See All (17)
Late Notice Actual Costs Claim Process. Within 56 days (or such other period as the parties may agree) of receipt by the CVL IM of a Late Notice Actual Costs Claim Notice, the CVL IM shall notify the Train Operator that either: it agrees that the Late Notice Actual Costs Claim Trigger is satisfied and agrees to the amount of the Late Notice Actual Costs claimed by the Train Operator in the Late Notice Actual Costs Claim Notice, in which case the CVL IM shall also pay such Late Notice Actual Costs to the Train Operator within 56 days of receipt by the CVL IM of the relevant Late Notice Actual Costs Claim Notice; or it agrees that the Late Notice Actual Costs Claim Trigger is satisfied but does not agree to the amount of the Late Notice Actual Costs claimed by the Train Operator in the Late Notice Actual Costs Claim Notice, in which case the CVL IM shall: (if it has not already done so) commence negotiations with the Train Operator in respect of its Late Notice Actual Costs and shall continue such negotiations in good faith until they are concluded or until the Late Notice Actual Costs are determined in accordance with Clause 13; and pay to the Train Operator its Late Notice Actual Costs within 28 days of those Late Notice Actual Costs being agreed or determined in accordance with Clause 13 (as the case may be); or it does not agree that the Late Notice Actual Costs Claim Trigger is satisfied, in which case the matter shall be immediately referred for determination in accordance with Clause 13, and if it is determined in accordance with Clause 13 that the Late Notice Actual Costs Claim Trigger is satisfied then the CVL IM shall: (if it has not already done so) commence negotiations with the Train Operator in respect of its Late Notice Actual Costs and shall continue such negotiations in good faith until they are concluded or until the Late Notice Actual Costs are determined in accordance with Clause 13; and pay to the Train Operator such Late Notice Actual Costs within 28 days of those Late Notice Actual Costs being agreed or determined in accordance with Clause 13 (as the case may be).
Sample 1Sample 2See All (4)
Late Notice Actual Costs Claim Process. Within 56 days (or such other period as the parties may agree) of receipt by Nexus of a Late Notice Actual Costs Claim Notice, Nexus shall notify the Train Operator that either:
Sample 1Sample 2Sample 3
Late Notice Actual Costs Claim Process. Within 56 days (or such other period as the parties may agree) of receipt by the CVL IM of a Late Notice Actual Costs Claim Notice, the CVL IM shall notify the Train Operator that either: it agrees that the Late Notice Actual Costs Claim Trigger is satisfied and agrees to the amount of the Late Notice Actual Costs claimed by the Train Operator in the Late Notice Actual Costs Claim Notice, in which case the CVL IM shall also pay such Late Notice Actual Costs to the Train Operator within 56 days of receipt by the CVL IM of the relevant Late Notice Actual Costs Claim Notice; or
Sample 1

Related to Late Notice Actual Costs Claim Process

  • Notice of Overpayment If the Contractor receives a vendor overpayment notice or a letter communicating the existence of an overpayment from DSHS, the Contractor may protest the overpayment determination by requesting an adjudicative proceeding. The Contractor’s request for an adjudicative proceeding must:

  • Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.

  • Project Reports; Completion Report 1. The Recipient shall monitor and evaluate the progress of the Project and prepare Project Reports in accordance with the provisions of Section 2.06 of the Standard Conditions and on the basis of indicators agreed with the World Bank. Each Project Report shall cover the period of one (1) calendar semester, and shall be furnished to the World Bank not later than one (1) month after the end of the period covered by such report.

  • Actual Costs The Consultant can invoice the City for no more than the actual cost of each subconsultant plus a specified markup not to exceed 5 percent.

  • Underpayment In the event of a change which results in an underpayment to an employee, the employee shall be properly compensated on or before the next possible paycheck following discovery of the error. Upon request, the District shall provide the employee with specific written explanation for the underpayment through the Payroll Contact Person at the employee’s location.

Time is Money Join Law Insider Premium to draft better contracts faster.