Funding Baseline (Previously Question 8 of Program Description) Sample Clauses

Funding Baseline (Previously Question 8 of Program Description). Please estimate the cost of care for the members of the target population under the current service arrangements. This will form the baseline against which you will measure changes in funding under your RBS program. For each type of service, indicate the funding source and estimate the average annual per person cost of care. The table below shows the baseline data for the financial analysis: Key Measures Baseline Data RBS Goal Reduced Length of Stay (group care) 24.8 mos 12 mos Reduced Reliance on Out of State Placements 6 eligible youth currently out of state 60% reduction Reduced Hospitalizations 3.1 episodes 41 days total* *some are admin days 0 admin days Reduced AWOL Incidents 3.2 episodes 28 days total 50% reduction following first 90 days of care Improved Permanency: Increased placement stability in family care (6.2 years in xxxxxx care) 3 placements - 80% of youth remain in RBS until goals met The above goals set treatment baselines for financial analysis including cost for services and AFDC-FC cost neutrality for both the State and the County. The costs below are the costs for the current population: Type of Service Funding Source Average annual cost per client Level 14 Residential Placement Level 14 Residential Day Rate Day Treatment Intensive Med Support Services Specialized School Services AFDC-FC MH Realignment Funds EPSDT EPSDT PL 94-142 $80,328 $26,280 $39,600 $2,000 $30,660 ($146/day for 210 days)
AutoNDA by SimpleDocs

Related to Funding Baseline (Previously Question 8 of Program Description)

  • Disclosure Statement for Xxxx IRAs 1. Am I Eligible to Contribute to a Xxxx XXX? Anyone with compensation income whose Modified Adjusted Gross Income (AGI) does not exceed the limits described below is eligible to contribute to a Xxxx XXX. (For convenience, all future references to compensation are deemed to mean “earned income” in the case of a self- employed individual.) Employers may also contribute to Xxxx IRAs established for the benefit of their employees. You may also establish a Xxxx XXX to receive rollover contributions or transfers from another Xxxx XXX or, in some cases, from a Traditional IRA. A Qualified Rollover Contribution can be made to a Xxxx XXX and is a distribution from an IRA that meets the requirements of section 408(d)(3), a rollover from a designated Xxxx account described in section 402A, or a rollover from an eligible retirement plan as described in section 402(c)(8)(B).

  • Please see the current Washtenaw Community College catalog for up-to-date program requirements Secondary / Post-Secondary Program Alignment Welding HIGH SCHOOL COURSE SEQUENCE 9th Grade 10th Grade 11th Grade 12th Grade English 9 Algebra I World History/Geography Biology World Language Phys Ed/Health English 10 Geometry U.S. History/Geography Physics or Chemistry World Language Visual/Performing/Applied Arts English 11 Algebra II Civics/Economics Welding English 12 Math Credit Science Credit Welding WASHTENAW COMMUNITY COLLEGE Welding Associate in Applied Science Semester 1 Math Elective(s)* 3 WAF 105 Introduction to Welding Processes 2 WAF 111 Oxy-fuel Welding 4 WAF 112 Shielded Metal Arc Welding 4 Semester Total 13 Semester 2 Speech Elective(s) 3 WAF 106 Blueprint Reading for Welders 3 WAF 123 Advanced Oxy-fuel Welding 4 WAF 124 Advanced Shielded Metal Arc Welding 4 Semester Total 14 Semester 3 Arts/Human. Elective(s) 3 Computer Lit. Elective(s) 3 WAF 215 Advanced Gas Tungsten Arc Welding 4 WAF 288 Gas Metal Arc Welding 4 Semester Total 14 Semester 4 WAF 200 Layout Theory Welding 3 WAF 210 Welding Metallurgy 3 Soc. Sci. Elective(s) 3 WAF 226 Specialized Welding Procedures 4 Semester Total 13 Semester 5 Nat. Sci. Elective(s) 4 WAF 227 Basic Fabrication 3 WAF 229 Shape Cutting Operations 3 Writing Elective(s) 3 Semester Total 13 Program Totals 67

  • DISTRIBUTION OF CONTRACTOR PRICE LIST AND CONTRACT APPENDICES Contractor shall provide Authorized Users with electronic copies of the Contract, including price lists and Appendices, upon request. OGS CENTRALIZED CONTRACT MODIFICATIONS Contract Updates will be handled as provided in Appendix C – Contract Modification Procedures.

  • Evaluation Schedule CLIENT REFERENCES The Tenderer shall provide details of his performance on each of the previous projects listed in the “Relevant Experience” returnable schedule. “Client Reference Scorecards” will be completed by each of the respective Clients for the projects listed in the “Relevant Experience” returnable schedule. The following are to be completed by the Client and Principal Agent and is to be supported in each case by a letter of award and the works completion certificate. Both Client and Principal Agent must sign and stamp the documents, failure to obtain both signatures and stamps will result in no allocation of points. PROJECT NAME and SCOPE OF WORK: Principal agent: ................................................................................................................................. Client: .. ..............................................................................................................................................

  • Schedule for Completing Agreement Closeout Activities Provide All Draft and Final Written Products on a CD-ROM or USB memory stick, organized by the tasks in the Agreement. Products: • Final Meeting Agreement Summary (if applicable) • Schedule for Completing Agreement Closeout Activities • All Draft and Final Written Products

  • Project Location & Description The Project, for which the provision of financial assistance is the subject of this Agreement, is hereby described as follows:

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.

  • Development Schedule The Project shall substantially comply with the specific timetables and triggers for action set forth in Article 5 of this Agreement. The parties acknowledge that, as provided in G.S. 160A-400.25(b), the failure to meet a commencement or completion date shall not, in and of itself, constitute a material breach of this Agreement pursuant to G.S. 160A-400.27 but must be judged based upon the totality of the circumstances.

  • Compliance Between Individual Contract and Master Agreement An individual contract between the Board and an individual employee, heretofore or hereafter executed, shall be subject to and consistent with the terms and conditions of this Agreement. If an individual contract contains any language inconsistent with this Agreement, this Agreement during its duration shall be controlling.

Time is Money Join Law Insider Premium to draft better contracts faster.