Extension of Transition Sample Clauses

Extension of Transition. (a) Subject to Section 3.1.6(b) below, at any time and from time to time during the Transition, the Commission shall have the right to require that Provider cease, suspend or delay all or any part of the Transition or alter the timing for all or any part of the Transition if the Commission reasonably determines that any part of the Transition Services pose a material risk or hazard to the Commission’s business interests, all without any increase in the Payments payable by the Commission or any additional costs or expenses charged to the Commission, provided, however, that Provider shall be entitled to recover from the Commission any costs reasonably incurred by Provider as a result of a Non-Provider Transition Delay Event that is specified in clause (i) or
Sample 1
AutoNDA by SimpleDocs

Related to Extension of Transition

  • Extension of Agreement Prior to the original expiration date of this Agreement, the Parties mutually agree to extend this Agreement to the February 15 extension date identified in Paragraph VIII(A). The Parties acknowledge that no further extensions of this Agreement are authorized. Xxxxxxxxx has hereunto signed on this Day of , 20 . Landowner(s): The Secretary of the Department of Agriculture, acting and through his or her authorized representative has executed this Contract on behalf of the United States of America on this Day of , 20 . THE UNITED STATES OF AMERICA BY: NONDISCRIMINATION STATEMENT The U.S. Department of Agriculture (USDA) prohibits discrimination in all its programs and activities on the basis of race, color, national origin, age, disability, and where applicable, sex, marital status, familial status, parental status, religion, sexual orientation, genetic information, political beliefs, reprisal, or because all or a part of an individual’s income is derived from any public assistance program. (Not all prohibited bases apply to all programs.) Persons with disabilities who require alternative means for communication of program information (Braille, large print, audiotape, etc.) should contact USDA’s TARGET Center at 0 (000) 000-0000 (voice and TDD). To file a complaint of discrimination, write to USDA, Director, Office of Civil Rights, 0000 Xxxxxxxxxxxx Xxxxxx, XX., Xxxxxxxxxx, XX 00000-0000 or call (000) 000-0000 (voice) or (000) 000-0000 (TDD). USDA is an equal opportunity provider and employer. PRIVACY ACT STATEMENT

  • EXTENSION OF USE The Contract may be extended to additional States or governmental jurisdictions upon mutual written agreement between New York State (the lead contracting State) and the Contractor. Political subdivisions and other authorized entities within each participating State or governmental jurisdiction may also participate in the Contract if such State normally allows participation by such entities. New York State reserves the right to negotiate additional minimum NYS Vehicle Discounts based on any increased volume generated by such extensions.

  • Extension of Time If the Executive shall be in violation of any provision of this Article 6, then each time limitation set forth in this Article 6 shall be extended for a period of time equal to the period of time during which such violation or violations occur. If the Company seeks injunctive relief from such violation in any court, then the covenants set forth in this Article 6 shall be extended for a period of time equal to the pendency of such proceeding including all appeals by the Executive.

  • Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:

  • Extension of Term Provided Exporter's goods and services are in demand and Exporter is processing sales generating Transaction Fees, as set forth in Section 6, within fifteen (15) years from the Effective Date, Exporter shall have an option to (a) continue with its membership under Section 2 at no additional fee, or (b) option of developing single point of sales, distribution, networking, and logistics facilities separate and distinct from AmericaTowne for a mutually agreeable reduced rate, which shall be agreed upon in writing prior to thirty (30) days from the termination of fifteen (15) years from the Effective Date. The Exporter has the option of choosing option (b) above at its discretion.

  • No Extension of Time If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures set forth herein.

  • Delays and Extension of Time If the Contractor is delayed at any time in the progress of providing goods and/or services by an act or neglect of the District, or by changes ordered in the work, or by labor disputes, strikes, insurrections, fire, acts of God; unusual but well documented and excusable delays in performance, or other causes beyond the Contractor’s control, or by delay authorized by the District, then the contract Term of service may be extended by a contract amendment for such reasonable time as the District and the Contractor may agree.

  • Extension of Probation The probationary period shall be regarded as part of the testing process and shall be utilized for closely observing the employee's work, for securing the most effective adjustment of an employee to a new position, and for rejecting any probationary employee whose performance does not meet the required standards of work. The Fire Chief may recommend, and the City Manager may extend, an employee's normal probationary period by a maximum of six months in two-month increments.

  • EXTENSION OF THE SEASON Concessionaire may request to extend the Period of Operation either prior to the Saturday before Memorial Day and/or after Labor Day. All requests shall be submitted to both the Office of Leases & Concessions and the Area Superintendent, in writing, at the addresses set forth in Subparagraph 5(B) and Paragraph 49, respectively, fifteen (15) calendar days in advance of the proposed implementation. Approval of this request shall be within Department’s sole discretion. Concessionaire shall be deemed to not have permission to extend the Period of Operation without written approval from the Office of Leases & Concessions and the Area Superintendent. Additional compensation to Department for the extended period shall be calculated by Department on a monthly basis or prorated by day and must be submitted by check made payable to “Treasurer – State of New Jersey” and sent to the address set forth in Subparagraph 5(B). The additional compensation must be received by Department in advance of operation for the extended period.

  • Extension of Probationary Period The probationary period shall not be extended except in the case of extended illness or injury or compelling personal situation during which time the employee was unable to work. In such cases, the probationary period may be extended for the length of time the ill or injured employee was unable to work.

Time is Money Join Law Insider Premium to draft better contracts faster.