Extension of Time. If the Executive shall be in violation of any provision of this Article 6, then each time limitation set forth in this Article 6 shall be extended for a period of time equal to the period of time during which such violation or violations occur. If the Company seeks injunctive relief from such violation in any court, then the covenants set forth in this Article 6 shall be extended for a period of time equal to the pendency of such proceeding including all appeals by the Executive.
Extension of Time. STATE may extend the time for performance of this contract upon written request from PURCHASER or upon STATE's own motion. Except as provided in Section 29, a request for extension: • shall be accompanied by the written consent to an extension of the security by PURCHASER's surety; • shall state the date to which the extension is desired, the area of the operations to be affected, and the reason(s) for the extension; and • must be received by STATE no later than 30 days prior to the expiration date of this contract unless the need for extension occurred within the 30 days prior to the expiration date, in which case the request must be received prior to the expiration date. Requests for extension may be granted for any reason except changes in timber market conditions. STATE shall grant a request for an extension only when it determines that extension would be in the best interests of STATE. In no event shall an extension exceed one year. When STATE grants a request for extension, it may condition that grant upon any condition it determines is necessary to protect the interests of the STATE. Such conditions may include, but may not be limited to, the following:
Extension of Time. In the event that Executive breaches any covenant, obligation or duty in this Section 13, any such duty, obligation, or covenants to which the parties agreed by this Section 13 shall automatically toll from the date of the first breach, and all subsequent breaches, until the resolution of the breach through private settlement, judicial or other action, including all appeals. The duration and length of Executive’s duties and obligations as agreed by this Section 13 shall continue upon the effective date of any such settlement, or judicial or other resolution.
Extension of Time. While it is anticipated that all applications of the Contractor for additional time or extensions of the Material Completion Date would have been filed and determined by the Owner prior to the Material Completion Date, the Contractor may, within 10 days after the Material Completion Date, file for any additional extensions of time pursuant to Section 3, Part 4, and the collection, but not the accrual, of Liquidated Damages shall be suspended until the Owner’s decision. Should such a belated application be filed after the 10-day period, the Owner, in its sole discretion, may continue to collect Liquidated Damages. Should the Owner grant any applications for extension of time and the Material Completion Date, Liquidated Damages shall be adjusted accordingly.
Extension of Time. If the Surveyor determines or reasonably anticipates that the work authorized in a work authorization cannot be completed before the specified completion date, the Surveyor shall promptly notify the State. In its sole discretion, the State may agree to extend the work authorization period by joint execution of a supplemental to a work authorization.
Extension of Time. The time limits within which action must be taken or a decision made as specified in this procedure may be extended by mutual written consent of the parties involved. A statement of the duration of such extension of time must be signed by both parties involved at the step to be extended.
Extension of Time. 8. (1) The arbitrator arbitrators or umpire (as the case may be) of any submission to arbitration hereunder is hereby empowered upon application by either party hereto to grant any interim extension of time or date referred to herein which having regard to the circumstances may reasonably be required in order to preserve the rights of either or both the parties hereunder and an award in favour of the Company may in the name of the Minister grant any further extension of time for that purpose.
Extension of Time. Time shall be of the essence of this Agreement. Any time limits specified in this Agreement may be extended with the consent in writing of both the Owner and the Municipality, but no such extension of time shall operate or be deemed to operate as an extension of any other time limit, and time shall be deemed to remain of the essence of this Agreement notwithstanding any extension of any time limit.