Environmental Conditions A Phase I environmental site assessment (or update of a previous Phase I and or Phase II environmental site assessment) and, with respect to certain Mortgage Loans, a Phase II environmental site assessment (collectively, an “ESA”) meeting ASTM requirements conducted by a reputable environmental consultant in connection with such Mortgage Loan within 12 months prior to its origination date (or an update of a previous ESA was prepared), and such ESA (i) did not identify the existence of Recognized Environmental Conditions (as such term is defined in ASTM E1527-05 or its successor, hereinafter “Environmental Condition”) at the related Mortgaged Property or the need for further investigation, or (ii) if the existence of an Environmental Condition or need for further investigation was indicated in any such ESA, then at least one of the following statements is true: (A) an amount reasonably estimated by a reputable environmental consultant to be sufficient to cover the estimated cost to cure any material noncompliance with applicable Environmental Laws or the Environmental Condition has been escrowed by the related Mortgagor and is held or controlled by the related lender; (B) if the only Environmental Condition relates to the presence of asbestos-containing materials, radon in indoor air, lead based paint or lead in drinking water, the only recommended action in the ESA is the institution of such a plan, an operations or maintenance plan has been required to be instituted by the related Mortgagor that can reasonably be expected to mitigate the identified risk; (C) the Environmental Condition identified in the related environmental report was remediated, abated or contained in all material respects prior to the date hereof, and, if and as appropriate, a no further action, completion or closure letter or its equivalent, was obtained from the applicable governmental regulatory authority (or the Environmental Condition affecting the related Mortgaged Property was otherwise listed by such governmental authority as “closed” or a reputable environmental consultant has concluded that no further action or investigation is required); (D) an environmental policy or a lender’s pollution legal liability insurance policy that covers liability for the Environmental Condition was obtained from an insurer rated no less than “A-” (or the equivalent) by Xxxxx’x, S&P and/or Fitch; (E) a party not related to the Mortgagor was identified as the responsible party for the Environmental Condition and such responsible party has financial resources reasonably estimated to be adequate to address the situation; or (F) a party related to the Mortgagor having financial resources reasonably estimated to be adequate to address the situation is required to take action. To Seller’s knowledge, except as set forth in the ESA, there is no Environmental Condition at the related Mortgaged Property.
ACCESS TO PLANTS AND PROPERTIES Seller shall comply with all the rules and regulations established by Buyer for access to and activities in and around premises controlled by Buyer or Buyer’s customer.
Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.
– OTHER SPECIAL CONDITIONS The following additional special conditions apply to this agreement:
HHSC SPECIAL CONDITIONS The terms and conditions of these Special Conditions are incorporated into and made a part of the Contract. Capitalized items used in these Special Conditions and not otherwise defined have the meanings assigned to them in HHSC Uniform Terms and Conditions -Grant- Version 2.16.1
SPECIAL CONDITIONS A submitted appeal must;
Supplemental Conditions 1. All individuals involved, and all others who might possibly contribute to the acceptable adjustment of a grievance, are authorized and urged to testify with full assurance that no reprisal will follow by reason of such participation.
ADDITIONAL CONSTRUCTIONS The Promoter undertakes that it has no right to make additions or to put up additional structure(s) anywhere in the Project after the building plan has been approved by the competent authority(ies) except for as provided in the Act.
CONSTRUCTION AND IMPROVEMENTS Concessionaire shall not affix, alter, or erect any permanent or temporary equipment, structures, buildings, or additions to the Concession Premises without first obtaining the prior written approval of Department.
Additional Conditions For each mediation or arbitration:
