Requesting Price Increase/Required Documentation Contractor must submit a written notification at least thirty (30) calendar days prior to the requested effective date of the change, setting the amount of the increase, along with an itemized list of any increased prices, showing the Contractor’s current price, revised price, the actual dollar difference and the percentage of the price increase by line item. Price change requests must include H-GAC Forms D Offered Item Pricing and E Options Pricing, or the documentation used to submit pricing in the original Response and be supported with substantive documentation (e.g. manufacturer's price increase notices, copies of invoices from suppliers, etc.) clearly showing that Contractor's actual costs have increased per the applicable line item bid. The Producer Price Index (PPI) may be used as partial justification, subject to approval by H-GAC, but no price increase based solely on an increase in the PPI will be allowed. This documentation should be submitted in Excel format to facilitate analysis and updating of the website. The letter and documentation must be sent to the Bids and Specifications manager, Xxxxxxx Xxxxxx, at Xxxxxxx.Xxxxxx@x-xxx.xxx Review/Approval of Requests If H-GAC approves the price increase, Contractor will be notified in writing; no price increase will be effective until Contractor receives this notice. If H-GAC does not approve Contractor’s price increase, Contractor may terminate its performance upon sixty (60) days advance written notice to H-GAC, however Contractor must fulfill any outstanding Purchase Orders. Termination of performance is Contractor’s only remedy if H-GAC does not approve the price increase. H-GAC reserves the right to accept or reject any price change request.
Rate Redetermination for Market Change In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.
Contract Renegotiation, Suspension, or Termination Due to Change in Funding If the funds DSHS relied upon to establish this Contract or Program Agreement are withdrawn, reduced or limited, or if additional or modified conditions are placed on such funding, after the effective date of this contract but prior to the normal completion of this Contract or Program Agreement:
Effective Date of Increase Price increases shall be effective upon final approval by the State, and may not be posted on the pricelist prior to receipt of final approval.
Automatic Renewal Limitation for TIPS Sales No TIPS Sale may incorporate an automatic renewal clause that exceeds month to month terms with which the TIPS Member must comply. All renewal terms incorporated into a TIPS Sale Supplemental Agreement shall only be valid and enforceable when Vendor received written confirmation of acceptance of the renewal term from the TIPS Member for the specific renewal term. The purpose of this clause is to avoid a TIPS Member inadvertently renewing an Agreement during a period in which the governing body of the TIPS Member has not properly appropriated and budgeted the funds to satisfy the Agreement renewal. Any TIPS Sale Supplemental Agreement containing an “Automatic Renewal” clause that conflicts with these terms is rendered void and unenforceable.
TERM, TERMINATION & SUSPENSION The Company may terminate this Agreement with You at any time for any reason, with or without cause. The Company specifically reserves the right to terminate this Agreement if You violate any of the terms outlined herein, including, but not limited to, violating the intellectual property rights of the Company or a third party, failing to comply with applicable laws or other legal obligations, and/or publishing or distributing illegal material. If You have registered for an account with Us, You may also terminate this Agreement at any time by contacting Us and requesting termination. At the termination of this Agreement, any provisions that would be expected to survive termination by their nature shall remain in full force and effect.
Availability of PHI for Amendment Modernizing Medicine shall provide PHI in EMA to Medical Practice for amendment, and incorporate any such amendments in the PHI (for so long as Modernizing Medicine maintains such information in the Designated Record Set), in accordance with this Addendum and as required by 45 C.F.R. § 164.526. If Modernizing Medicine receives a request for amendment to PHI directly from an Individual, Modernizing Medicine shall forward such request to Medical Practice within ten (10) business days. Medical Practice shall have the sole responsibility for determining whether to approve an amendment to PHI and to make such amendment.
TERMINATION DUE TO CHANGE IN FUNDING 35 In the event funding from HCA, MCO, State, Federal, or other sources is withdrawn, reduced, or limited 36 in any way after the effective date of this Contract and prior to its normal completion, either party may 37 terminate this Contract subject to re-negotiations.
Extension After Suspension When a suspension occurs through no fault of PURCHASER, PURCHASER may request an extension of time for performance of this contract, for a period not to exceed the period of operations that were suspended. The request for extension must be in writing and:
Rate Redetermination for Environmental Modification In the event of a contract modification under B8.33 or partial termination under B8.34, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber remaining immediately prior to the revision and the appraised unit value of Included Timber to be cut under the modification. The appraisal shall consider the estimated cost of any construction work listed in the Schedule of Items that was performed and abandoned. Tentative Rates and Flat Rates in effect at the time of the revision will be adjusted by said differences to become Current Contract Rates. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates, or differences for rates subject to B3.2, and Required Deposits shall be considered established under B3.1 for timber Scaled subsequent to the contract revision.
