Public Works Installation work which is considered public works is excluded from purchase under this Contract. Historically, the New York State Bureau of Public Works has maintained that installation, maintenance and repair of equipment attached to any wall, ceiling or floor or affixed by hard wiring or plumbing is public work. In contrast, installation of a piece of equipment which is portable or a “plug-in” free-standing unit would not be considered public work. Thus, this Contract does not authorize installation where the equipment becomes a permanent part of the building structure, or is otherwise incorporated into the fabric of the building (e.g., installation on a wall, ceiling or floor in a fixed location, or affixed by hard-wiring or plumbing). See Xxxxxxxx X, §00, Prevailing Wage Rates - Public Works and Building Services Contracts. For questions about whether a proposed installation constitutes public work, please contact the New York State Department of Labor’s Bureau of Public Work district office in your area. A listing of district offices and contact information is available at: xxxx://xxx.xxxxx.xx.xxx/workerprotection/publicwork/PWContactUs.shtm.
Department of Agriculture United States Department of Agriculture at 0-000-000-0000, 000-000-0000, or xxxx://xxx.xxxxx.xxx/plantind/ to determine those specific project sites located in the quarantined area or for any regulated article used on this project originating in a quarantined county. Regulated Articles Include
Department of Housing and Urban Development This includes a HUD produced video titled “The Basics of the Fair Housing Act” which can be accessed via YouTube at xxxxx://xxx.xxxxxxx.xxx/watch?v=egXPe7HT7tc. Relief for Complainant
CONTRACTOR California Department of General Services Use Only CONTRACTOR’S NAME (if other than an individual, state whether a corporation, partnership, etc.) BY (Authorized Signature) DATE SIGNED (Do not type) PRINTED NAME AND TITLE OF PERSON SIGNING ADDRESS STATE OF CALIFORNIA AGENCY NAME BY (Authorized Signature) DATE SIGNED (Do not type) PRINTED NAME AND TITLE OF PERSON SIGNING Exempt per: ADDRESS Exhibit A Project Summary & Scope of Work
ENVIRONMENT, SAFETY AND HEALTH PROTECTION (a) Seller shall perform this Agreement in a manner that ensures adequate protection for workers, the public, and the environment, and shall be accountable for actions of itself and its lower-tier subcontractors, agents and employees. Seller shall exercise a degree of care commensurate with the work and the associated hazards. Seller shall ensure that management of environment, safety and health (ES&H) functions and activities is an integral and visible part of Seller’s work planning and execution process. In the event that Xxxxxx fails to comply with this Agreement, Company may, without prejudice to any other legal or contractual rights, issue an order stopping all or any part of the work; thereafter a start order for resumption of work may be issued at Company’s discretion. Seller shall make no claim for an extension of time or for compensation or damages by reason of or in connection with such work stoppage. In addition, Company may require, in writing, that Seller remove from the work any employee the Company deems unsafe, incompetent, careless, or otherwise objectionable.
Department of Health and Human Services An employee notified of a positive controlled substance or alcohol test result may request an independent test of their split sample at the employee’s expense. If the test result is negative, the Employer will reimburse the employee for the cost of the split sample test. An employee who has a positive alcohol test and/or a positive controlled substance test may be subject to disciplinary action, up to and including dismissal, based on the incident that prompted the testing, including a violation of the drug and alcohol free work place rules.
Fire Safety 9.5.1 Residents found in violation of the following fire safety stipulations not only put themselves at risk but also jeopardizes the safety of the entire community.
ENVIRONMENTAL PROTECTION STANDARDS CONTRACTOR shall be in compliance with the Clean Air Act (Title 42 USC Section 7401 et seq.), the Clean Water Act (Title 33 USC Section 1251 et seq.), Executive Order 11738 and Environmental Protection Agency, hereinafter referred to as “EPA,” regulations (Title 40 CFR), as any may now exist or be hereafter amended. Under these laws and regulations, CONTRACTOR assures that:
Cooperation on forestry matters and environmental protection 1. The aims of cooperation on forestry matters and environmental protection will be, but not limited to, as follows: (a) establishing bilateral cooperation relations in the forestry sector; (b) developing a training program and studies for sustainable management of forests; (c) improving the rehabilitation and sustainable management of forest with the aim of increasing carbon sinks and reduce the impact of climate change in the Asia-Pacific region; (d) cooperating on the execution of national projects, aimed at: improving the management of forest plantations for its transformation for industrial purposes and environmental protection; (e) elaborating studies on sustainable use of timber; (f) developing new technologies for the transformation and processing of timber and non-timber species; and (g) improving cooperation in agro-forestry technologies. 2. To achieve the objectives of the Article 149 (Objectives), the Parties may focus, as a means of cooperation and negotiations on concluding a bilateral agreement on forestry cooperation between the two Parties. Such collaboration will be as follows: (a) exchanges on science and technology as well as policies and laws relating the sustainable use of forest resources; (b) cooperation in training programs, internships, exchange of experts and projects advisory; (c) advice and technical assistance to public institutions and organizations of the Parties on sustainable use of forest resources and environmental protection; (d) facilitating forest policy dialogue and technical cooperation under the Network of Sustainable Forest Management and Forest Rehabilitation in Asia- Pacific Region, initiated at the 15th Asia Pacific Economic Cooperation (APEC) Meeting; (e) encouraging joint studies, working visits, exchange of experiences, among others; and (f) others activities mutually agreed.
Information Technology Accessibility Standards Any information technology related products or services purchased, used or maintained through this Grant must be compatible with the principles and goals contained in the Electronic and Information Technology Accessibility Standards adopted by the Architectural and Transportation Barriers Compliance Board under Section 508 of the federal Rehabilitation Act of 1973 (29 U.S.C. §794d), as amended. The federal Electronic and Information Technology Accessibility Standards can be found at: xxxx://xxx.xxxxxx-xxxxx.xxx/508.htm.
