Cost for General Conditions Work Sample Clauses

Cost for General Conditions Work. CM/GC shall be paid on a cost reimbursable maximum not-to-exceed price basis as payment for the GC Work, including all labor, materials, and direct and indirect costs thereof. The maximum not-to-exceed amount for GC Work shall be established in each Early Work Amendment or the GMP Amendment, as applicable. To the extent any GC Work is otherwise described above in this Article 8, CM/GC’s compensation for the same is included in the Cost for GC Work and shall not otherwise be charged as Cost of the Work. (See Exhibit C). The Cost for GC Work, less 5% retainage thereon, shall be paid monthly on a reimbursable basis over the number of months of the scheduled Construction Phase, including any period of Early Work, commencing with the first progress billing after commencement of the scheduled Construction Phase or Early Work Period. However, no adjustment in the maximum amount payable for General Conditions Work will be made if the actual construction period or Early Work period is shorter or longer than the number of months scheduled for the Construction Phase or Early Work period, unless such period is extended because of an Owner-requested delay.
Sample 1Sample 2See All (5)
AutoNDA by SimpleDocs
Cost for General Conditions Work. Cost for General Conditions Work or GC Work shall mean that sum identified in Article 8.8 and/or Exhibit C.
Sample 1Sample 2Sample 3
Cost for General Conditions Work. CM/GC shall be paid a sum of $ for all services as stated in Exhibit C as payment for the GC Work, including all labor, materials, and direct and indirect costs thereof. To the extent any General Conditions Work is listed in Exhibit C and also otherwise described above in this Article 8, CM/GC’s compensation for the same is included in the Cost for GC Work and shall not otherwise be charged as Cost of the Work. The Cost for General Conditions Work, less 5% retainage thereon, shall be paid in equal installments monthly over the number of months of the scheduled Construction Phase, commencing with the first progress billing after commencement of the scheduled Construction Phase.
Sample 1
Cost for General Conditions Work. CM/GC shall be paid a sum of $ (to be established by GMP Amendment) for all services as stated in Exhibit C as payment for the GC Work, including all labor, materials, and direct and indirect costs thereof. To the extent any General Conditions Work is listed in Exhibit C and also otherwise described above in this Article 8, CM/GC’s compensation for the same is included in the Cost for GC Work and shall not otherwise be charged as Cost of the Work. The Cost for General Conditions Work, less 5% retainage thereon, shall be paid in equal installments monthly over the number of months of the scheduled Construction Phase, commencing with the first progress billing after commencement of the scheduled Construction Phase.
Sample 1
Cost for General Conditions Work. “Cost for General Conditions Work” means sums paid on a cost reimbursable maximum not-to-exceed price basis as described in Article 8.8 and as included in Exhibit E, Cost for General Conditions Work Breakout.
Sample 1

Related to Cost for General Conditions Work

  • General Conditions (i) Each party will make each payment or delivery specified in each Confirmation to be made by it, subject to the other provisions of this Agreement.

  • For General Conditions Costs Contractor’s Application for Payment shall be submitted on a Schedule of Values approved by the Owner and include complete copies of all receipts, invoices with check vouchers or other evidence of payment, payrolls, and any and all other evidence which Owner or its designated representatives shall deem necessary to support the amount requested. This information is subject to audit and payment for these costs is dependent on Owner’s receipt of accurate and complete records of all transactions. Owner may reduce the amount requested for General Conditions Costs in any Application for Payment if Owner, in its good faith judgment, determines that the unpaid balance of the General Conditions line item in the Schedule of Values is not sufficient to fund necessary General Conditions Costs for the remainder of the Project.

  • Application of General Conditions These General Conditions set forth the terms and conditions generally applicable to the Development Grant Agreement to the extent and subject to any modifications set forth in such agreement.”

  • General Condition The Aircraft will:

  • General Conditions Costs Construction Manager is entitled to receive payment for the actual cost of the allowable General Conditions items incurred after receipt of a Notice to Proceed with Construction from the Owner through Substantial Completion of the Project plus thirty (30) calendar days. Construction Manager is not entitled to reimbursement for General Conditions Costs incurred before receipt of the Notice to Proceed. General Conditions Costs incurred after Substantial Completion must be approved in advance by the Owner. Allowable General Conditions items are identified below and by attached exhibit. These items shall be included in the General Conditions cost amount shown as a line item in the Guaranteed Maximum Price Proposal and as detailed on the schedule of values. Items not specifically included below or in the exhibit will not be allowed as a General Condition costs.

  • General Project Description 2. Substation location.

  • Detailed Description of Services / Statement of Work Describe fully the services that Contractor will provide, or add and attach Exhibit B to this Agreement.

  • BUILDER’S RISK FOR CONSTRUCTION RENOVATION PROJECTS If the project is CONSTRUCTION RENOVATION of an existing structure, and the State has already determined that Contractor will not be obligated to obtain and maintain Builder’s Risk insurance, then the following provisions apply:

  • GENERAL WORKING CONDITIONS The District has empowered school communities to make decisions at the school level in return for accountability for results. To maximize the likelihood of success, each school must be permitted to implement programs that meet the needs of its students and community. Through a school-based decision-making process, each school will define the staff working conditions necessary for student success. School leadership teams will create and publish annual “school operational plans” which will outline working conditions of staff in the building. Such operational plans will be subject to the Superintendent’s review and approval.

  • Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.

Time is Money Join Law Insider Premium to draft better contracts faster.