Compensation for Multiple Medical Conditions Sample Clauses

Compensation for Multiple Medical Conditions. Any Eligible Claimant who, at the time of submission of a claim, meets the eligibility requirements for more than one Designated Medical Condition shall be entitled to receive the amount of compensation applicable only to the most highly compensated medical condition for which the Eligible Claimant qualifies, except that an Eligible Claimant who meets the eligibility requirements for Rupture and another Designated Medical Condition is entitled to compensation for both Rupture and the Designated Medical Condition, to be calculated in accordance with the ratios indicated in the Compensation Schedule, attached as Exhibit A-1 to the Agreement.
Sample 1Sample 2
AutoNDA by SimpleDocs
Compensation for Multiple Medical Conditions. Any Eligible Claimant who is a Primary Breast Implant Claimant who, at the time of submission of a claim, meets the eligibility requirements for more than one category under the Medical Conditions List shall be entitled to receive the amount of compensation applicable only to the most highly compensated medical condition for which the Eligible Claimant qualifies, except that an Eligible Claimant who meets the eligibility requirements for Rupture and another medical condition is entitled to compensation for both the Rupture and the medical condition to be calculated in accordance with the ratios indicated in the Compensation Schedule, attached as Exhibit A-1 to the Agreement.
Sample 1

Related to Compensation for Multiple Medical Conditions

  • COMPENSATION ANALYSIS After the expiration of the second (2nd) Renewal Term of this Agreement, if any, a Compensation Analysis may be performed. At such time, based on the reported Total Gross Revenue, performance of the Concession, and/or Department’s existing rates for similarly- performing operations, Department may choose to increase the Concession Payment for the following Renewal Term(s), if any.

  • Compensation for Delay The time allowed for carrying out the work, as entered in the tender form, shall be strictly observed by the contractor and shall be deemed to be the essence of the contract and shall be reckoned from the fifteenth day after the date on which the order to commence the work is issued to the contractor, for a work where completion is up to 6 months For works, for which the completion period is beyond six months: - The period will be reckoned from the thirtieth day after the date on which the order to commence the work is issued to contractor .The work shall throughout the stipulated period of contract be proceeded with all due diligence, keeping in view that time is the essence of the contract. The contractor shall be bound in all cases, in which the time allowed for any work exceeds one month, to complete 1/8th of the whole work before 1/4th of the whole time allowed under the contract has elapsed, 3/8th of the work before 1/2 of such time has elapsed and 3/4th of the work before 3/4th of such time has elapsed. In the event of the contractor failing to comply with the above conditions, the Commissionor/CMO shall levy on the contractor, as compensation an amount equal to: 0.5% (zero point five percent) of the value of work (contract sum) for each week of delay, provided that the total amount of compensation under this provision of the clause shall be limited to 6% (six percent) of the value of work. (Contract sum) Provided further that if the contractor fails to achieve 30% (thirty percent) progress in half (1/2) of original or validly extended period of time (reference clause 5 below) the contract shall stand terminated after due notice to the contractor and his contract finallised, with xxxxxxx money and or security deposit forfeited and levy of further compensation at the rate of 10% of the balance amount of contract left incomplete, either from the bill, and or from available security/performance guarantee or shall be recovered as "Arrears of land revenue". The decision of the Competent Authority in the matter of grant of extension of time only (reference clause 5 below) shall be final, binding and conclusive. But he has no right to change either the rate of compensation or reduce and or condone the period of delay- once such an order is passed by him (on each extension application of the contractor). It shall not be open for a revision. Where the Commissioner/CMO or Competent Authority or Commissioner/CMO as the case may decides that the contractor is liable to pay compensation for not giving proportionate progress under this clause and the compensation is recommended during the intermediate period, such compensation shall be kept in deposit and shall be refunded if the contractor subsequently makes up the progress for the lost time, within the period of contract including extension granted, if any. failing which the compensation amount shall be forfeited in favour of the Nagar Xxxxx/Nagar Palika Parishad/Nagar Panchayat Clause 3 -:Action when the work is left incomplete abandoned or delayed beyond the time limit permitted by the Commissioner/CMO or Competent Authority: -

  • COMPENSATION FOR CONSTRUCTION PHASE SERVICES 5.1 For the Construction Manager’s performance of the Work as described in Section 2.3, the Owner shall pay the Construction Manager the Contract Sum in current funds. The Contract Sum is the Cost of the Work as defined in Section 6.1.1 plus the Construction Manager’s Fee.

  • Compensation for Convenience Termination If City shall terminate for its convenience as herein provided, City shall compensate Consulting Engineer/Architect for all Engineering/Architectural Services satisfactorily completed to date of its receipt of the termination notice and any additional Engineering/Architectural Services requested by City to bring the Project to reasonable termination. Compensation shall not include anticipatory profit or consequential damages, neither of which will be allowed.

  • PRESCRIPTION MEDICATION BENEFITS, LIMITATIONS AND EXCLUSIONS The following items are limited or excluded from your Prescription Medication coverage:

  • Compensation for Unused Sick Leave 1. Employees who enter County service after July 1, 1979, shall not be eligible for compensation for any of their unused sick leave credits.

  • Overtime Eligibility and Compensation Employees are eligible for overtime compensation under the following circumstances:

  • Compensation for Basic Services A. Owner shall make payment for Part I and Part II services monthly. The payments shall be in proportion to the progress of Architect's work. Final payment for each phase shall become due and payable upon completion and approval by Owner of that phase of Architect's work.

  • A-E Compensation and Extra Work 1.5.1. For the PROJECTS/SERVICES authorized under this CONTRACT, A-E shall be compensated in accordance with the following:

  • Eligibility for Overtime Compensation (a) Overtime compensation rates for all hours worked in excess of the workday and workweek identified below shall be as follows:

Time is Money Join Law Insider Premium to draft better contracts faster.