Warranty and Guarantee The Contractor shall warrant and guarantee the materials and work to be free of defects for a period of two (2) years after the City’s final acceptance of the entire Project. The Contractor shall be liable for any costs, losses, expenses, or damages, including consequential damages, suffered by the City resulting from defects in the Contractor’s work including, but not limited to, the cost of materials and labor expended by the City in making emergency repairs and the cost of engineering, inspection, and supervision by the City. The Contractor shall hold the City harmless from any and all claims, which may be made against the City as a result of any defective work, and the Contractor shall defend any claims at its own expense. Where materials or procedures are not specified in the Contract, the City will rely on the professional judgment of the Contractor to make the appropriate selections.
Inspection, Rejection and Guarantee C16.1 The Authority or its authorised representatives may inspect or test the Goods either complete or in the process of manufacture during normal business hours on reasonable notice at the Contractor’s premises and the Contractor shall provide all reasonable assistance in relation to any such inspection or test free of charge, including further testing and inspection if reasonably required by the Authority. No failure to make complaint at the time of such inspection or test and no approval given during or after such inspection or test shall constitute a waiver by the Authority of any rights or remedies in respect of the Goods and the Authority retains the right to reject the Goods.
Contractor Guaranties Contractor shall:
Performance Guarantee 9.4.1 The Concessionaire shall, for the performance of its obligations hereunder during the Concession Period, provide to the Authority no later than [90] days prior to expiry of the Performance Security, an irrevocable and unconditional guarantee from a Bank for a sum equivalent to Rs. ***** crore (Rupees ***** crore)7 in the form set forth in Schedule-FF (the “Performance Guarantee”). Until such time the Performance Guarantee is provided by the Concessionaire pursuant hereto and the same comes into effect, notwithstanding anything contained in clause 9.3 the Performance Security shall remain in force and effect, and upon such provision of the Performance Guarantee pursuant hereto, the Authority shall release the Performance Security to the Concessionaire.
The Service Guarantee Due to circumstances beyond the control of the Service, particularly delays in handling and posting payments by Billers or financial institutions, some transactions may take longer to be credited to your account. The Service will bear responsibility for any late payment related charges up to $50.00 should a payment post after its Due Date as long as the payment was scheduled in accordance with the Section 2 of the Bill Payment Terms (Payment Scheduling).
Service Guarantee 8.1. All pesticides used by Prokill are approved under the Control of Pesticides Regulations and have been assessed for any hazard under C.O.S.H.H. (Information on request). You are covered by our Unique Service Promise, which means if we do not deliver the minimum contracted annual visits, we {Ref: YCM/00251276-3} will refund 100% of that years’ Service Agreement subject to payment terms being met.
Consumer Guarantees (a) Under the Australian Consumer Law, consumers (as defined in the ACL) have the benefit of certain Consumer Guarantees:
Performance Guarantees Contractor agrees to provide the County the performance guarantees specified in Attachment A and to pay any penalties incurred in accordance with the terms of Attachment A.
PRICE GUARANTEE The prices established herein shall prevail for the term of this Agreement, except in the event of a general market decline in prices of such commodities at any time during the period of this Contract, the Contractor agrees that the State of Mississippi shall receive full benefit of such decline. The State Bureau of Financial Control shall not approve any account nor order and direct payment of any account for the purchase of any commodity covered by this Contract when the purchase price is in excess of the maximum price fixed in this Agreement.
Construction Contract If federal funds are included as part of the financing of the non-OPWC portion of the Project, federal law may prevail, including, but not limited to, application of Xxxxx Xxxxx prevailing wage rates, the Xxxxxxxx “Anti-Kickback” Act, the Contract Work Hours and Safety Standards Act, and any federal environmental regulations. Recipient is solely responsible for ensuring compliance with federal requirements applicable to its Local Subdivision Contribution. Notwithstanding the above, the following provisions apply to construction contracts under this Agreement:
