Contract Extensions This Contract may be extended on an annual basis beyond the Initial Term if the Local Board successfully meets the terms of the Contract for at least three or more years as determined by the State Board.
Delays and Extensions The CONSULTANT agrees that no charges or claim for damages shall be made by it for any minor delays from any cause whatsoever during the progress of any portion of the Services specified in this Contract. Such delays, if any, shall be compensated for by an extension of time for such period as may be determined by the LPA subject to the CONSULTANT's approval, it being understood, however, that permitting the CONSULTANT to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the LPA of any of its rights herein. In the event of substantial delays or extensions, or change of any kind, not caused by the CONSULTANT, which causes a material change in scope, character or complexity of work the CONSULTANT is to perform under this Contract, the LPA at its sole discretion shall determine any adjustments in compensation and in the schedule for completion of the Services. CONSULTANT must notify the LPA in writing of a material change in the work immediately after the CONSULTANT first recognizes the material change.
Extensions and Renewals All extensions or renewals of leaves shall be applied for and granted in writing.
Time Extensions 2.03.1 If Contractor requests an extension of time to complete its performance, then the Director, in consultation with the CPO, may, in his or her sole discretion, extend the time so long as the extension does not exceed 90 days. The extension must be in writing but does not require amendment of this Agreement. Contractor is not entitled to damages for delay(s) regardless of the cause of the delay(s).
F8 Extension of Initial Contract Period F8.1 The Authority may, by giving written notice to the Contractor, extend the Contract for a further period up to the date set out in the Form of Contract. The provisions of the Contract will apply throughout any such extended period.
Extension Terms County may, at its sole option, extend the term of this Agreement beyond the Initial Term for up to ___ additional one-year terms at the same rates and under the same terms provided for herein (each such period being an “Extension Term”). County shall notify Contractor of its election for an Extension Term(s) as provided for in §6.
TAM Extension Service The TAM Extension Service is an extension of a Red Hat Enterprise Linux TAM Service to provide additional technical knowledge such as SAP implementations on Red Hat Enterprise Linux. The TAM Extension Service requires a separate active and paid standard TAM Service Subscription.
Extension of Initial Contract Period 31.1 Subject to clause 13 (Price Adjustment on Extension of the Initial Contract Period), the Authority may, by giving written notice to the Contractor not less than three (3) Month(s) prior to the last day of the Initial Contract Period, extend the Contract for such further period as may be specified in the notice. The provisions of the Contract will apply (subject to any Variation or adjustment to the Contract Price pursuant to clause 13) throughout any such extended period.
No Extension of Time If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures set forth herein.
Contract Extension The City may, in its sole discretion, unilaterally exercise an option to extend the Contract as described in the Contract Documents. In addition, the City may, in its sole discretion, unilaterally extend the Contract on a month-to-month basis following contract expiration if authorized under Charter section 99 and the Contract Documents. Contractor shall not increase its pricing in excess of the percentage increase described in the Contract.
