Using Construction Funds for Environmental Commitments to be Implemented during Construction Sample Clauses

Using Construction Funds for Environmental Commitments to be Implemented during Construction. In general, the implementation of environmental commitments during construction, such as flagging or monitoring, are paid for with construction funds, typically the 01C funding phase. As construction funds are generally not yet open at the time that the decision is made, the HPT Staff needs to work proactively with the Environmental Planner and PM to ensure that a plan is in place for addressing the consultant task order when the construction funds are available. When the work will be done on Environmental Planning’s on-call contract, the Environmental Planning Project Delivery Manager is included in the process. If the work is to be done under a Project Development on-call, the project PM is included in the process. An email from the Resident Engineer is needed in order to utilize construction funds. As the RE is generally not assigned to the project until the contract goes out to bid, the HPT Lead will coordinate with the Environmental Planner.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs

Related to Using Construction Funds for Environmental Commitments to be Implemented during Construction

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • Delays during construction Without prejudice to the provisions of Clause 10.3 (ii), in the event the Contractor does not achieve any of the Project Milestones or the Authority’s Engineer shall have reasonably determined that the rate of progress of Works is such that Completion of the Project Highway is not likely to be achieved by the end of the Scheduled Completion Date, it shall notify the same to the Contractor, and the Contractor shall, within 15 (fifteen) days of such notice, by a communication inform the Authority’s Engineer in reasonable detail about the steps it proposes to take to expedite progress and the period within which it shall achieve the Project Completion Date.

  • Project Construction Budget The project construction cost allowance specifically stated in writing as the ‘revised’ or ‘current’ ‘Project Construction Budget’ by the Trustees at each applicable phase of plan development.

  • Early Construction of Base Case Facilities Developer may request Connecting Transmission Owner to construct, and Connecting Transmission Owner shall construct, subject to a binding cost allocation agreement reached in accordance with Attachment S to the ISO OATT, including Section 25.8.7 thereof, using Reasonable Efforts to accommodate Developer’s In-Service Date, all or any portion of any System Upgrade Facilities or System Deliverability Upgrades required for Developer to be interconnected to the New York State Transmission System which are included in the Base Case of the Class Year Study for the Developer, and which also are required to be constructed for another Developer, but where such construction is not scheduled to be completed in time to achieve Developer’s In-Service Date.

  • Maintenance during Construction Period (i) During the Construction Period, the Contractor shall maintain, at its cost, the existing lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at no time materially inferior as compared to their condition on Appointed Date, and shall undertake the necessary repair and maintenance works for this purpose; provided that the Contractor may, at its cost, interrupt and divert the flow of traffic if such interruption and diversion is necessary for the efficient progress of Works and conforms to Good Industry Practice; provided further that such interruption and diversion shall be undertaken by the Contractor only with the prior written approval of the Authority’s Engineer which approval shall not be unreasonably withheld. For the avoidance of doubt, it is agreed that the Contractor shall at all times be responsible for ensuring safe operation of the Project Highway. It is further agreed that in the event the Project includes construction of a bypass or tunnel and realignment of the existing carriageway, the Contractor shall maintain the existing highway in such sections until the new Works are open to traffic.

  • Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.

  • Construction With Other Parts Of The Tariff This ISA shall not be construed as an application for service under Part II or Part III of the Tariff.

  • Award of Construction Contract and Other Future Contracts 6.2.1 A-E is hereby informed that provisions of the Public Contract Code, the Political Reform Act of 1974, other statutes, regulations, and COUNTY policy prohibit, as an impermissible conflict of interest, the award of a contract for the construction of the project(s) on which A-E performed architectural-engineering services under this A-E CONTRACT. A-E is hereby informed that these statutes and regulations could also prohibit the award to A-E of design or other contracts on future phases related to tasks performed by A-E under this CONTRACT. This prohibition applies also to a subcontractor of or parent company of the firm that performed architectural-engineering tasks under this CONTRACT.

  • Construction Phase - Administration of the Construction Contract 1.6.1 The Construction Phase shall commence with the acceptance of the Construction Manager’s Guaranteed Maximum Price (or acceptance of a partial Guaranteed Maximum Price for a stage or phase) and issuance of a Notice to Proceed with Construction Services and terminate sixty (60) days after Final Payment to the Contractor is made, or when all of Architect/Engineer’s services have been satisfactorily performed, whichever occurs later.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure:

Time is Money Join Law Insider Premium to draft better contracts faster.