Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
Alterations and Tenant’s Property Any alterations, additions, or improvements made to the Premises by or on behalf of Tenant, including additional locks or bolts of any kind or nature upon any doors or windows in the Premises, but excluding installation, removal or realignment of furniture systems (other than removal of furniture systems owned or paid for by Landlord) not involving any modifications to the structure or connections (other than by ordinary plugs or jacks) to Building Systems (as defined in Section 13) (“Alterations”) shall be subject to Landlord’s prior written consent, which may be given or withheld in Landlord’s sole discretion if any such Alteration affects the structure or Building Systems and shall not be otherwise unreasonably withheld, conditioned or delayed. Tenant may construct nonstructural Alterations in the Premises without Landlord’s prior approval if the aggregate cost of all such work in any 12 month period does not exceed $75,000.00 (a “Notice-Only Alteration”), provided Tenant notifies Landlord in writing of such intended Notice-Only Alteration, and such notice shall be accompanied by plans, specifications, work contracts and such other information concerning the nature and cost of the Notice-Only Alteration as may be reasonably requested by Landlord, which notice and accompanying materials shall be delivered to Landlord not less than 15 business days in advance of any proposed construction. If Landlord approves any Alterations, Landlord may impose such conditions on Tenant in connection with the commencement, performance and completion of such Alterations as Landlord may deem appropriate in Landlord’s reasonable discretion. Any request for approval shall be in writing, delivered not less than 15 3115 Xxxxxxxxxx/Erasca - Page 14 business days in advance of any proposed construction, and accompanied by plans, specifications, bid proposals, work contracts and such other information concerning the nature and cost of the alterations as may be reasonably requested by Landlord, including the identities and mailing addresses of all persons performing work or supplying materials. Landlord’s right to review plans and specifications and to monitor construction shall be solely for its own benefit, and Landlord shall have no duty to ensure that such plans and specifications or construction comply with applicable Legal Requirements. Tenant shall cause, at its sole cost and expense, all Alterations to comply with insurance requirements and with Legal Requirements and shall implement at its sole cost and expense any alteration or modification required by Legal Requirements as a result of any Alterations. Other than in connection with any Notice-Only Alterations, Tenant shall pay to Landlord, as Additional Rent, on demand an amount equal to 2% of all charges incurred by Tenant or its contractors or agents in connection with any Alteration to cover Landlord’s overhead and expenses for plan review, coordination, scheduling and supervision. Before Tenant begins any Alteration, Landlord may post on and about the Premises notices of non-responsibility pursuant to applicable law. Tenant shall reimburse Landlord for, and indemnify and hold Landlord harmless from, any expense incurred by Landlord by reason of faulty work done by Tenant or its contractors, delays caused by such work, or inadequate cleanup. Tenant shall furnish security or make other arrangements reasonably satisfactory to Landlord to assure payment for the completion of all Alterations work free and clear of liens, and shall provide (and cause each contractor or subcontractor to provide) certificates of insurance for workers’ compensation and other coverage in amounts and from an insurance company satisfactory to Landlord protecting Landlord against liability for personal injury or property damage during construction. Upon completion of any Alterations, Tenant shall deliver to Landlord: (i) sworn statements setting forth the names of all contractors and subcontractors who did the work and final lien waivers from all such contractors and subcontractors; and (ii) “as built” plans for any such Alteration. Except for Removable Installations (as hereinafter defined), all Installations (as hereinafter defined) shall be and shall remain the property of Landlord during the Term and following the expiration or earlier termination of the Term, shall not be removed by Tenant at any time during the Term, and shall remain upon and be surrendered with the Premises as a part thereof. Notwithstanding the foregoing, Landlord may, at the time its approval of any such Installation is requested, or at the time it receives notice of a Notice-Only Alteration, notify Tenant that Landlord requires that Tenant remove such Installation upon the expiration or earlier termination of the Term, in which event Tenant shall remove such Installation in accordance with the immediately succeeding sentence. Upon the expiration or earlier termination of the Term, Tenant shall remove (i) all wires, cables or similar equipment which Tenant has installed in the Premises or in the risers or plenums of the Building, (ii) any Installations for which Landlord has given Tenant notice of removal in accordance with the immediately preceding sentence, and (iii) all of Tenant’s Property (as hereinafter defined), and Tenant shall restore and repair any damage caused by or occasioned as a result of such removal, including, without limitation, capping off all such connections behind the walls of the Premises and repairing any holes. During any restoration period beyond the expiration or earlier termination of the Term, Tenant shall pay Rent to Landlord as provided herein as if said space were otherwise occupied by Tenant. If Landlord is requested by Tenant or any lender, lessor or other person or entity claiming an interest in any of Tenant’s Property to waive any lien Landlord may have against any of Tenant’s Property, and Landlord consents to such waiver, then Landlord shall be entitled to be paid as administrative rent a fee of $1,000 per occurrence for its time and effort in preparing and negotiating such a waiver of lien.
Condition of the Leased Property Lessee acknowledges receipt and delivery of possession of the Leased Property. Lessee has examined and otherwise has knowledge of the condition of the Leased Property and has found the same to be satisfactory for its purposes hereunder. Lessee is leasing the Leased Property “as is” in its present condition. Lessee waives any claim or action against Lessor in respect of the condition of the Leased Property. LESSOR MAKES NO WARRANTY OR REPRESENTATION, EXPRESS OR IMPLIED, IN RESPECT OF THE LEASED PROPERTY, OR ANY PART THEREOF, EITHER AS TO ITS FITNESS FOR USE, DESIGN OR CONDITION FOR ANY PARTICULAR USE OR PURPOSE OR OTHERWISE, AS TO THE QUALITY OF THE MATERIAL OR WORKMANSHIP THEREIN, LATENT OR PATENT, IT BEING AGREED THAT ALL SUCH RISKS ARE TO BE BORNE BY LESSEE. LESSEE ACKNOWLEDGES THAT THE LEASED PROPERTY HAS BEEN INSPECTED BY LESSEE AND IS SATISFACTORY TO IT. Provided, however, to the extent permitted by law, Lessor hereby assigns to Lessee all of Lessor’s rights to proceed against any predecessor in title (other than any Affiliate of Lessee, which conveyed the Property to Lessor) for breaches of warranties or representations or for latent defects in the Leased Property. Lessor shall fully cooperate with Lessee in the prosecution of any such claim, in Lessor’s or Lessee’s name, all at Lessee’s sole cost and expense. Lessee hereby agrees to indemnify, defend and hold harmless Lessor from and against any claims, obligations and liabilities against or incurred by Lessor in connection with such cooperation.
Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.
Leased Property and Term 2.1 Leased Property Upon and subject to the terms and conditions hereinafter set forth, Landlord leases to Tenant and Tenant leases from Landlord all of Landlord's right, title and interest in and to all of the following (collectively, the "Leased Property"):
TENANT'S ESTOPPEL CERTIFICATE From time to time, upon written request of Landlord, Tenant shall execute, acknowledge and deliver to Landlord or its designee, a written certificate stating (a) the date this Lease was executed, the Commencement Date of the Term and the date the Term expires; (b) the date Tenant entered into occupancy of the Premises; (c) the amount of Rent and the date to which such Rent has been paid; (d) that this Lease is in full force and effect and has not been assigned, modified, supplemented or amended in any way (or, if assigned, modified, supplemented or amended, specifying the date and terms of any agreement so affecting this Lease); (e) that this Lease represents the entire agreement between the parties with respect to Tenant’s right to use and occupy the Premises (or specifying such other agreements, if any); (f) that all obligations under this Lease to be performed by Landlord as of the date of such certificate have been satisfied (or specifying those as to which Tenant claims that Landlord has yet to perform); (g) that all required contributions by Landlord to Tenant on account of Tenant’s improvements have been received (or stating exceptions thereto); (h) that on such date there exist no defenses or offsets that Tenant has against the enforcement of this Lease by Landlord (or stating exceptions thereto); (i) that no Rent or other sum payable by Tenant hereunder has been paid more than one (1) month in advance (or stating exceptions thereto); (j) that a currently valid Letter of Credit has been deposited with Landlord, stating the original amount thereof and any increases or decreases thereto; and (k) any other matters evidencing the status of this Lease that may be required either by a lender making a loan to Landlord to be secured by a deed of trust covering the Building or the Project or by a purchaser of the Building or the Project. Any such certificate delivered pursuant to this Paragraph 30 may be relied upon by a prospective purchaser of Landlord’s interest or a mortgagee of Landlord’s interest or assignee of any mortgage upon Landlord’s interest in the Premises. If Tenant shall fail to provide such certificate within ten (10) days of receipt by Tenant of a written request by Landlord as herein provided, such failure shall, at Landlord’s election, constitute a Default under this Lease, and Tenant shall be deemed to have given such certificate as above provided without modification and shall be deemed to have admitted the accuracy of any information supplied by Landlord to a prospective purchaser or mortgagee.
Construction of Tenant Improvements by Tenants Agents Construction Contract; Cost Budget. Prior to Tenant's execution of ---------------------------------- the construction contract and general conditions with Contractor (the "Contract"), Tenant shall submit the Contract to Landlord for its approval, which approval shall not be unreasonably withheld or delayed. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, of the final costs to be incurred, or which have been incurred, as set forth more particularly in Sections 2.2.1.1 through ---------------- 2.2.1.8 above, in connection with the design and construction of the Tenant ------- Improvements to be performed by or at the direction of Tenant or the Contractor (which costs form a basis for the amount of the Contract, if any (the "Final Costs"). Prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with a completion bond in an amount equal to the Final Costs to ensure Landlord of the completion of the Tenant Improvements.
Tenant’s Remedies Notwithstanding any other provision of this Lease, if any default hereunder by Landlord is not cured within the applicable cure period provided in Paragraph 20(c) or any other applicable CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. cure period provided in this Lease (including any Mortgagee’s additional cure period), Tenant’s exclusive remedies shall be (i) an action for specific performance, or (ii) an action for actual damages. Notwithstanding any other provision of this Lease, the liability of Landlord to Tenant for any breach or default by Landlord under the terms of this Lease, or for any other matter related to this Lease or to the Premises or Project, shall be limited to Tenant’s actual direct, but not consequential, damages therefor, and any judgment against Landlord in connection therewith shall be recoverable only from the interest of Landlord in the Buildings. Tenant hereby waives any claim for damages for any disturbance, loss of business, nuisance, injury or inconvenience to or interference with Tenant’s business, any loss of occupancy or quiet enjoyment of the Premises, and any other loss arising from Landlord’s entry and acts pursuant to Paragraph 18 or otherwise with respect to any act, omission or breach of Landlord. Without limiting the preceding sentence, in no event shall Landlord be liable to Tenant for any consequential damages, including, without limitation, any losses arising from any interruption of Tenant’s business, or for lost profits, or for charges or expenses which continue but would have been earned if the business had gone on without interruption, or for any other loss, claim, cost, expense or damage which would be covered by a standard policy of business interruption insurance. Landlord, or if Landlord is a partnership its partners whether general or limited, or if Landlord is a corporation its directors, officers or shareholders, or if Landlord is a limited liability company its members or managers, shall never be personally liable for any such judgment. Any lien obtained to enforce such judgment and any levy of execution thereon shall be subject and subordinate to any Mortgage (excluding any Mortgage which was created as part of an effort to defraud creditors, i.e., a fraudulent conveyance); provided, however that any such judgment and any such levy of execution thereon shall not be subject or subordinated to any Mortgage that is created or recorded in the official records of the county in which the Project is located after the date of the judgment giving rise to such lien. Landlord’s interest in the Buildings shall include any insurance proceeds received by Landlord which are not controlled by any Mortgagee or other lender. Tenant hereby waives the benefit of any Laws granting it (A) the right to perform Landlord’s obligations, or (B) the right to terminate this Lease or withhold Rent on account of any Landlord default, including, without limitation, Sections 1932(1), 1941 and 1942 of the California Civil Code.
Landlord’s Retention of Contractor Landlord shall independently retain the Contractor to perform the Tenant Improvement Work in accordance with the Approved Construction Drawings.
Landlords and Tenants Property All fixtures, machinery, equipment, improvements and appurtenances attached to, or built into, the Premises at the commencement of, or during the Term, whether or not placed there by or at the expense of Tenant, shall become and remain a part of the Premises; shall be deemed the property of Landlord (the “Landlord’s Property”), without compensation or credit to Tenant; and shall not be removed by Tenant at the Expiration Date unless Landlord requires their removal (including, but not limited to, Alterations pursuant to Section 11). Further, any personal property in the Premises on the Commencement Date, movable or otherwise, unless installed and paid for by Tenant, shall also constitute Landlord’s Property and shall not be removed by Tenant. For purposes of this Lease, any references to “Tenant’s Property” shall mean any personal property for which Tenant has itself paid or manufactured, together with any machinery and equipment for which Tenant has paid and that is not attached to, or built into, the Premises. In no event shall Tenant remove any of the following materials or equipment from the Premises without Landlord’s prior written consent (which consent may be given or withheld in Landlord’s sole discretion): any power wiring or power panels, lighting or lighting fixtures, heaters, air conditioners or any other HVAC equipment, fencing or security gates, or other similar building operating equipment. At or before the Expiration Date, or the date of any earlier termination, Tenant, at its expense, shall remove from the Premises all of Tenant’s Property and any Alterations that Landlord requires be removed pursuant to Section 11, and Tenant shall repair (to Landlord’s reasonable satisfaction) any damage to the Premises or the Property resulting from either or both of such installation and removal. Any other items of Tenant’s Property that remain in the Premises after the Expiration Date, or following an earlier termination date, may, at the option of Landlord, be deemed to have been abandoned, and in such case, such items of Tenant’s Property may be retained by Landlord as its property or be disposed of by Landlord, in Landlord’s sole and absolute discretion and without accountability, at Tenant’s expense. Notwithstanding the foregoing, if Tenant is in default under the terms of this Lease, Tenant may remove Tenant’s Property from the Premises only upon the express written direction of Landlord.
