Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Annual Compliance Statements (a) The Master Servicers, the Special Servicers, the Certificate Administrator, the Trustee (but only to the extent set forth in the last sentence of this paragraph), any Additional Servicer and each Servicing Function Participant (if such Servicing Function Participant is a servicer contemplated by Item 1108(a)(2)(i), (ii) or (iii) of Regulation AB) (each, a “Certifying Servicer”) shall and the Master Servicers and the Special Servicers shall (i) with respect to any Additional Servicer or Servicing Function Participant (if such Servicing Function Participant is a servicer contemplated by Item 1108(a)(2)(i), (ii) or (iii) of Regulation AB) that is a Designated Sub-Servicer of such party, use commercially reasonable efforts to cause, and (ii) with respect to any other Additional Servicer or Servicing Function Participant (if such Servicing Function Participant is a servicer contemplated by Item 1108(a)(2)(i), (ii) or (iii) of Regulation AB), cause, each Additional Servicer and Servicing Function Participant (other than any party to this Agreement) with which it has entered into a servicing relationship with respect to the Mortgage Loans to, deliver to the Depositor, the Certificate Administrator, the Trust Advisor (in the case of a Special Servicer only), the Rule 17g-5 Information Provider (who shall promptly post such report to the Rule 17g-5 Information Provider’s Website pursuant to Section 8.12(c) of this Agreement) on or before March 1st (subject to a grace period through March 15th) of each year, commencing in 2015 (or, in the case of an Additional Servicer or Servicing Function Participant with respect to a Special Servicer, such party shall provide such Officer’s Certificate to such Special Servicer on or before March 1st (subject to a grace period through March 5th)), an Officer’s Certificate stating, as to the signer thereof, that (A) a review of such Certifying Servicer’s activities during the preceding calendar year or portion thereof and of such Certifying Servicer’s performance under this Agreement, or the applicable sub-servicing agreement or primary servicing agreement in the case of an Additional Servicer, has been made under such officer’s supervision and (B) to the best of such officer’s knowledge, based on such review, such Certifying Servicer has fulfilled all its obligations under this Agreement, or the applicable sub-servicing agreement or primary servicing agreement in the case of an Additional Servicer, in all material respects throughout such year or portion thereof, or, if there has been a failure to fulfill any such obligation in any material respect, specifying each such failure known to such officer and the nature and status thereof. The Certificate Administrator, shall prior to March 1st of each year, commencing in 2015, contact the Trustee and inquire as to whether any Advance was required to be made by the Trustee during the preceding calendar year, and if no such Advance was required to be made by the Trustee, then the Trustee shall not be required to deliver any compliance statement required by this Section 11.12(a) for such period.
Quality Assurance Requirements There are no special Quality Assurance requirements under this Agreement.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
Technical Objections to Grievances It is the intent of both parties to this agreement that no grievance shall be defeated merely because of a technical error other than time limitations in processing the grievance through the grievance procedure. To this end an arbitration board shall have the power to allow all necessary amendments to the grievance and the power to waive formal procedural irregularities in the processing of a grievance in order to determine the real matter in dispute and to render a decision according to equitable principles and the justice of the case.
Offense Level Calculations i. The base offense level is 7, pursuant to Guideline § 2B1.1(a)(1).
Child Abuse Reporting Requirements A. Grantees shall comply with child abuse and neglect reporting requirements in Texas Family Code Chapter 261. This section is in addition to and does not supersede any other legal obligation of the Grantee to report child abuse.
CONTRACT COMPLIANCE REQUIREMENT The HUB requirement on this Contract is 0%. The student engagement requirement of this Contract is 0 hours. The Career Education requirement for this Contract is 0 hours. Failure to achieve these requirements may result in the application of some or all of the sanctions set forth in Administrative Policy 3.10, which is hereby incorporated by reference.
