Remedies for Failure to Prosecute Work Sample Clauses

Remedies for Failure to Prosecute Work. If, in the reasonable judgment of the County, DBT shall (a) fail, refuse or neglect to supply a sufficiency of workers or to deliver the Materials or Equipment with such promptness as to prevent the delay in the progress of the Work, (b) fail in any respect to commence and diligently prosecute the Work and proceed to the point to which DBT shall proceed in accordance with the Construction Schedule in order to achieve Substantial Completion in accordance with the Construction Schedule, (c) fail to commence, prosecute, finish, deliver or install the different portions of the Work on time as herein specified in accordance with the Construction Schedule, or (d) fail in the performance of any of the material covenants of the Contract Documents, then the County shall have the right to direct DBT to accelerate the Work to comply with the Construction Schedule, including, providing additional labor or expediting deliveries of Materials, performing overtime, additional shifts or re- sequencing the Work without adjustment to the GMP. The County shall, after having provided DBT written notice and a reasonable opportunity to cure, and without waiving any other rights or remedies, have the right to withhold progress payments and supplement DBT's forces with Separate Contractors or to seek other redress for DBT's default. ARTICLE7 COUNTY'S RESPONSIBILITIES
Sample 1
AutoNDA by SimpleDocs

Related to Remedies for Failure to Prosecute Work

  • Remedies for Contractor Breach Pertaining to contract-related issues, it is the responsibility of both the Agency and the Contractor to communicate with each in as clear and complete a manner as possible. If at any time during the term of this contract the Agency or the Contractor is not satisfied with any issue, it is the responsibility of that party to deliver to the other party communication, in writing, fully detailing the issue and corrective action (please note that the Agency has the right to issue unilateral addendums to this contract, but the Contractor does not have the same right). The other party shall, within 10 days, respond in writing to the other party (however, the Agency shall retain the right to, if conditions warrant, require the Contractor to respond in a shorter period of time). Further, the Agency shall, at a minimum, employ the following steps in dealing with the Contractor as to any performance issues:

  • Remedies for Default (a) Enterprise Services’ rights to suspend and terminate Contractor’s rights under this Master Contract are in addition to all other available remedies.

  • Remedy for failure to insure If the Concessionaire shall fail to effect and keep in force all insurances for which it is responsible pursuant hereto, the Authority shall have the option to either keep in force any such insurances, and pay such premia and recover the costs thereof from the Concessionaire, or in the event of computation of a Termination Payment, treat an amount equal to the Insurance Cover as deemed to have been received by the Concessionaire.

  • Waiver and Cumulative Remedies No failure or delay by either party in exercising any right under this Agreement shall constitute a waiver of that right. Other than as expressly stated herein, the remedies provided herein are in addition to, and not exclusive of, any other remedies of a party at law or in equity.

  • Exclusive Remedies Subject to Section 9.12, the parties acknowledge and agree that their sole and exclusive remedy with respect to any and all claims (other than claims arising from intentional fraud on the part of a party hereto in connection with the transactions contemplated by this Agreement) for any breach of any representation, warranty, covenant, agreement or obligation set forth herein or otherwise relating to the subject matter of this Agreement, shall be pursuant to the indemnification provisions set forth in this ARTICLE VII. In furtherance of the foregoing, each party hereby waives, to the fullest extent permitted under the law, any and all rights, claims and causes of action for any breach of any representation, warranty, covenant, agreement or obligation set forth herein or otherwise relating to the subject matter of this Agreement it may have against the other parties hereto and their affiliates and each of their respective representatives arising under or based upon any law, rule or regulation, except pursuant to the indemnification provisions set forth in this ARTICLE VII. Nothing in this Section 7.05 shall limit any person’s right to seek and obtain any equitable relief to which any person shall be entitled pursuant to Section 9.12 or to seek any remedy on account of any intentional fraud by any party hereto.

  • Contractor’s Remedies If the State is in breach of any provision of this Contract and does not cure such breach, Contractor, following the notice and cure period in §14.B and the dispute resolution process in §16 shall have all remedies available at law and equity. If a Purchasing Entity is in breach of a provision of an Order, Contractor shall have all remedies available to it under that Order and available at law and equity.

  • Exclusive Remedy The foregoing shall constitute the Parties' sole and exclusive remedies and obligations with respect to a third party claim of intellectual property infringement arising out of the conduct of business under this Agreement.

  • Breach; STATE’s Remedies If PURCHASER fails to remedy a violation within the time allowed and as instructed by STATE, or if PURCHASER fails to complete work as required within any interim contract completion date or by the contract expiration date, PURCHASER is in breach, and STATE may pursue any and all remedies available to STATE. Such remedies include, but are not limited to: (1) making a claim on each bond provided by PURCHASER; (2) suing PURCHASER for all damages STATE incurs as a result of PURCHASER's breach; (3) suing PURCHASER for specific performance of the contract; (4) terminating the contract and reselling the breached contract; and (5) declaring PURCHASER in default, in accordance with the provisions of OAR 629- 032-0000 through 0070 (as adopted at the time of contracting and as may be amended later by the agency having jurisdiction or authority over such activities). The provisions of OAR 629-032-0000 through 0070, and any future amendments, are incorporated into this contract and made a permanent part hereof by reference as though fully set forth herein. THE PROVISIONS OF OAR 629-032-0000 THROUGH 0070 ARE IN ADDITION TO, AND NOT IN LIEU OF, ANY OTHER REMEDIES STATE MAY HAVE FOR THE PURCHASER'S BREACH OF CONTRACT. NOTICES, PLANS, AND INSPECTIONS Section 35. Work Responsibility and Acceptance. Prior to the completion and final acceptance of operations, PURCHASER shall be held responsible for, and shall correct any injury or damage to, the operations or any part of the operations, from any cause whatsoever, unless adjustment is made pursuant to Section 28. STATE shall make final inspection of operations done by PURCHASER within 10 calendar days after written notification is received by STATE from PURCHASER stating that the operation is complete. Following inspection, STATE shall notify PURCHASER of acceptance in writing. If the operation is not acceptable to STATE, STATE shall advise PURCHASER in writing of the particular defects to be remedied before final acceptance by STATE can be made.

  • Breach and Remedies for Breach 14 10.1 Liquidated Damages Schedule and Schedule Amendments.

  • BREACH; REMEDIES Notwithstanding anything to the contrary in this Agreement, the Participant agrees and acknowledges that the breach of this Section would cause substantial loss to the goodwill of the Company and/or its Affiliates, and cause irreparable harm for which there is no adequate remedy at law. Further, because the Participant’s employment with the Employer is personal and unique, because damages alone would not be an adequate remedy and because of the Participant’s access to the Confidential Information, the Company and/or its Affiliates shall have the right to enforce this Section, including any of its provisions, by injunction, specific performance, or other equitable relief, without having to post bond or prove actual damages, and without prejudice to any other rights and remedies that the Company and/or its Affiliates may have for a breach of this Section, including, without limitation, money damages. The Participant agrees and acknowledges that notwithstanding the arbitration provisions in this Agreement, the Company may elect to file and pursue claims which arise from or relate to the Participant’s actual or threatened breaches of this Section in state or federal court of competent jurisdiction. The Participant shall be liable to pay all costs, including reasonable attorneys’ and experts’ fees and expenses, that the Company and/or its Affiliates may incur in enforcing or defending this Section, whether or not litigation is actually commenced and including litigation of any appeal taken or defended by the Company and/or its Affiliates where the Company and/or its Affiliates succeed in enforcing any provision of this Section.

Time is Money Join Law Insider Premium to draft better contracts faster.