Corrective Work. Consultant shall complete all Services, including deliverables, as required in the SOW to Agency’s satisfaction. If Agency, using reasonable discretion, determines that the Services or associated deliverables, or both, are unacceptable, Agency shall notify Consultant in writing of the deficiency. Within 7 calendar days (unless a different timeframe is agreed to by the Parties) of receipt of the deficiency notification Consultant shall respond to Agency outlining how the deficiency shall be corrected. Consultant shall correct any deficiencies in the Services and deliverables to Agency’s satisfaction without further compensation. If resolution is not achieved, Agency may withhold other payments until deficiencies have been corrected to the standard of care for such Services or deliverables (see PA Part II, Section 6.a, Professional Standard of Care). Agency shall not unreasonably withhold payment. For disputes related to deficiencies or standard of care and potential Errors and Omissions, see PA Part II, Section 23, Dispute Resolution and Errors & Omissions Claims Process, and Exhibit I, Errors & Omissions (E&O) Claims Process.
Corrective Work. Contractor shall complete all Services, including Deliverables, as required in the SOW to Agency’s satisfaction. If Agency, in its sole discretion, determines that the Services or associated Deliverables, or both, are unacceptable, Agency shall notify Contractor in writing of the deficiency. Within 7 calendar days (unless a different timeframe is agreed to by the Parties) of receipt of the deficiency notification Contractor shall respond to Agency outlining how the deficiency shall be corrected. Contractor shall correct any deficiencies in the Services and Deliverables to Agency’s satisfaction without further compensation. If resolution is not achieved, Agency may withhold other payments until deficiencies have been corrected to meet Contract requirements. Agency shall not unreasonably withhold payment.
Corrective Work. Representatives of the Secretary may make periodic inspection of the Project and the records of the City as may be deemed necessary or desirable. The City will direct or cause its contractor to accomplish any corrective action or work required by the Secretary’s representative as needed for a determination of federal participation. The Secretary does not undertake (for the benefit of the City, the contractor, the consultant, or any third party) the duty to perform day-to- day detailed inspection of the Project or to catch the contractor’s errors, omissions or deviations from the final Design Plans.
Corrective Work. When any Work does not conform to the Contract Documents, Contractor shall make the necessary corrections so that the Work will so conform. Such corrections shall be accomplished within the time period approved by the Project Manager. Failure to complete such required corrections within the time period required shall constitute a breach of the Contract. The County’s review, approval or acceptance of, or payment for any work shall not be construed as a waiver of any rights under this Contract or any cause of action arising out of the performance of this Contract.
Corrective Work. Consultant shall complete all Services, including Deliverables, as required in the Contract to Agency’s satisfaction. If Agency, using reasonable discretion, determines that the Services or associated deliverables, or both, are unacceptable, Agency shall notify Consultant in writing of the deficiency. Within 7 calendar days (unless a different timeframe is agreed to by the Parties) of receipt of the deficiency notification Consultant shall respond to Agency outlining how the deficiency shall be corrected. Consultant shall correct any deficiencies in the Services and Deliverables to Agency’s satisfaction without further compensation. Agency will not unreasonably withhold payment.
Corrective Work. In addition to any other guarantees or warrantees, the Contractor shall, after acceptance of the Work performed under this Contract, remedy without cost to the Department, any such defect, provided said defects in the judgment of the Department, or its successors having jurisdiction in the premises, are caused by defective or inferior materials, equipment or workmanship. If the corrective work is not completed within thirty
Corrective Work. Job Order Contractor shall remedy at Job Order Contractor’s expense: (A) any construction defect or failure of the Work to conform to the plans and specifications; (B) any Work damaged in fulfilling the terms and conditions of this Article; and
Corrective Work. Representatives of the Secretary may make periodic inspection of the Project and the records of the LPA as may be deemed necessary or desirable. The LPA will direct or cause its contractor to accomplish any corrective action or work required by the Secretary’s representative as needed for a determination of state participation. The Secretary does not undertake (for the benefit of the LPA, the Contractor, the Consultant, or any third party) the duty to perform day-to-day detailed inspection of the Project or to catch the Contractor’s errors, omissions or deviations from the final Design Plans.
Corrective Work. Within seven (7) Days of receipt by the DB Contractor of notice from the District specifying a failure of any of the Work to satisfy the DB Contractor’s Warranties, or of any Subcontractor representation, Warranty, guarantee, or obligation that the DB Contractor is responsible to enforce, the DB Contractor and the District shall mutually agree when and how the DB Contractor shall remedy such violation; provided, however, that in case of an emergency as indicated by the District in its notice requiring immediate curative action, the DB Contractor and the District shall agree on a remedy immediately upon notice by the District of such emergency. If the DB Contractor does not use its best efforts to proceed to effectuate such remedy within the agreed time, or if the DB Contractor and the District fail to reach such an agreement within such 7-Day period or immediately, in the case of emergency conditions, then the District, after notice to the DB Contractor, shall have the right to perform or have performed by third parties the necessary remedy, and the costs thereof shall be borne by the DB Contractor. The DB Contractor shall reimburse the District for such costs within 30 Days after the DB Contractor’s receipt of the invoice. The District may agree to accept Nonconforming Work in accordance with Section 7.6. The District and the DB Contractor shall conduct a walkthrough of the Site prior to expiration of the Warranty period and shall produce a Punch List of those items requiring Warranty Work. Contractor’s Costs of Correction of Work All costs of correcting such rejected Work, including additional testing and inspections, shall be deemed included in the Contract Price. The DB Contractor shall reimburse the District and pay the District’s expenses made necessary thereby within 30 Days after the DB Contractor’s receipt of invoice. The DB Contractor shall be responsible for obtaining any required Governmental Approvals or other consents from any other Person in connection with the Warranty Work.
Corrective Work. Design-Builder shall ensure correction and completion of all defective or incomplete Work. Such corrective Work shall be coordinated with and performed in such a manner as to minimize disruption to Owner's personnel facilities, and the operations of and at no cost to Owner.
