Temporary Space Upon reasonable prior notice from Tenant to Landlord, Landlord agrees to provide Tenant with temporary space (the "Temporary Space") on either the second floor of Building A or the second floor of Building B of a size and in a location to be mutually agreed upon by Landlord and Tenant for a period of time commencing no earlier than sixty (60) days from the date of Tenant's notice requesting that the Temporary Space be made available and expiring on the Commencement Date of this Lease. Tenant's occupancy of the Temporary Space shall be subject to all of the terms and conditions of this Lease to the extent appropriate, except that (i) Annual Fixed Rent for the Temporary Space shall be payable at the annual rate equal to the product of (x) $4.00 and (y) the rentable floor area of the Temporary Space, (ii) for the purposes of determining Tenant's payments on account of Landlord's Operating Expenses under Section 2.6 above and Landlord's Tax Expenses under Section 2.7 with respect to the Temporary Space, the "Rentable Floor Area of the Premises" shall be deemed to be the rentable floor area of the Temporary Space and (iii) the Temporary Space shall be delivered to Tenant in its "as is" condition and no improvement allowance or brokerage commission shall be payable with respect thereto. In addition, it is acknowledged and agreed that if Tenant shall elect to lease any Temporary Space hereunder, Tenant shall be occupying such Temporary Space while Landlord is proceeding with components of the Base Building Work in Buildings A and B and accordingly that Tenant shall use and occupy the Temporary Space in such as manner as to minimize any unreasonable interference with Landlord's performance of the Base Building Work. (signatures on next page) EXECUTED as a sealed instrument in two or more counterparts each of which shall be deemed to be an original. WITNESS: LANDLORD: BOSTON PROPERTIES LIMITED PARTNERSHIP By: Boston Properties, Inc., its general partner By: --/s/ Xxxxx RosenName: Xxxxx RosenTitle: Senior Vice President, Development TENANT ATTEST: By: By: /s/ Xxxxx Xxxxx Name: Name: Xxxxx Xxxxx Title: Secretary or Assistant Secretary Title: President or Vice President Hereto duly authorized By: Name: Title: Treasurer or Assistant Treasurer Hereto duly authorized EXHIBIT A DESCRIPTION OF SITE Those certain parcels of land (with the buildings thereon) situated in Bedford, Middlesex County, Massachusetts bounded and described as follows: PARCELS 1 and 2 Two certain parcels of land situated in Bedford, Middlesex County, Massachusetts, shown as Lot 1 and 2 on a plan entitled “Plan of Land in Bedford, Mass." dated March 1, 1962 by Xxxxxxx X. Xxxxxxx, Inc., recorded with Middlesex South District Deeds as Plan No. 487 of 1962 in Book 10022, Page 278, and together bound and described as follows: SOUTHWESTERLY by Xxxxxx Road by three lines measuring respectively two hundred eighty-three and 011100 (283.01) feet, twenty-one and 271100 (21.27) feet and four hundred eighty-three and 43/100 (483.43) feet; thence SOUTHERLY by said Xxxxxx Road by a curved line, one hundred nineteen and361100 (119.36) feet; thence SOUTHEASTERLY SOUTHERLY and SOUTHWESTERLY by said Xxxxxx Road by several lines measuring respectively two hundred ninety-three and 04/100 (293.04) feet, three hundred fifty three and 041100 (353.04) feet and two hundred twenty and 97/100 (220.97) feet; thence NORTHEASTERLY by the parcel marked "Reserved for Town of Bedford" on said plan, sixteen hundred forty-six and 81/100 (1646.81) feet; and thence NORTHWESTERLY by land now or late of The Worcester Corp., by two lines measuring respectively 305.23 feet and 294.24 feet and by land now or late of Xxxxxxx by two lines measuring respectively 170.33 feet and 64.34 feet, to the place of beginning. For Title see Deed recorded with the Middlesex South District Registry of Deeds in Book 12926, Page 233. PARCEL 3 A certain parcel of land situated in said Bedford, shown on a plan of land in Bedford, Mass.Dated June 5, 1961 by Xxxxxxx X. Xxxxxxx, Inc., Registered Land Surveyors, recorded with Middlesex South District Registry of Deeds at the end of Book 9844, bounded and described as follow: SOUTHWESTERLY by Xxxxxx Road, two hundred ninety-eight and 63/100 (298.63) feet; NORTHWESTERLY by land now or formerly of the Worcester Corporation, two hundred nine and 95/100 (209.95) feet; NORTHEASTERLY by land now or formerly of the Worcester Corporation, two hundred fifty and 57/100 (250.57) feet; and SOUTHEASTERLY by land now or formerly of Sinbad Realty Corporation by two lines respectively measuring one hundred seventy and 33/100 (170.33) feet and sixty-four and 341100(64.34) feet. Containing approximately 60,951 square feet of 1.4 acres according to said plan. For Title see Deed from Xxxxx X. Xxxxxxx and Xxxxxxxxx X. Xxxxxxx recorded with the Middlesex South District Registry of Deeds in Book 13539, Page 732. PARCEL 4 All right, title and interest in and to (i) that portion of Xxxxxx Road described in that certain Deed (a) recorded with the Middlesex South District Registry of Deeds in Book 14013, Page 486 and (b) filed with the Middlesex South Registry District of the Land Court as Document No. 599584 as to which Certificate of Title No. 161163 in Registration Book 936, Page 13 was issued; and
Temporary Taking If the whole or any part of the Leased Property (other than the fee) or of Lessee’s interest under this Lease is condemned by any Condemnor for its temporary use or occupancy (which shall mean a period not to exceed two years), this Lease shall not terminate by reason thereof, and Lessee shall continue to pay, in the manner and at the terms herein specified, the full amounts of Base Rent and Additional Charges. In addition, Lessee shall pay Percentage Rent at a rate equal to the average Percentage Rent during the last three (3) preceding Fiscal Years (or if three (3) Fiscal Years shall not have elapsed, the average during the preceding Fiscal Years). Except only to the extent that Lessee may be prevented from so doing pursuant to the terms of the order of the Condemnor, Lessee shall continue to perform and observe all of the other terms, covenants, conditions and obligations hereof on the part of Lessee to be performed and observed, as though such Condemnation had not occurred. In the event of any Condemnation as in this Section 15.6 described, the entire amount of any Award made for such Condemnation allocable to the Term of this Lease, whether paid by way of damages, rent or otherwise, shall be paid to Lessee. Lessee covenants that upon the termination of any such period of temporary use or occupancy it will, at its sole cost and expense (subject to Lessor’s contribution as set forth below), restore the Leased Property as nearly as may be reasonably possible to the condition in which the same was immediately prior to such Condemnation, unless such period of temporary use or occupancy extends beyond the expiration of the Term, in which case Lessee shall not be required to make such restoration. If restoration is required hereunder, Lessor shall contribute to the cost of such restoration that portion of its entire Award that is specifically allocated to such restoration in the judgment or order of the court, if any, and Lessee shall fund the balance of such costs in a manner reasonably satisfactory to Lessor.
Section 304 Temporary Securities Pending the preparation of definitive Securities of any series, the Company may execute, and upon Company Order the Trustee shall authenticate and deliver, temporary Securities which are printed, lithographed, typewritten, mimeographed or otherwise produced, in any authorized denomination, substantially of the tenor of the definitive Securities and, if applicable, having endorsed thereon the notations of Subsidiary Guarantees in lieu of which they are issued and with such appropriate insertions, omissions, substitutions and other variations as the officers executing such Securities and, if applicable, notations of Subsidiary Guarantees may determine, as evidenced by their execution of such Securities and notations of Subsidiary Guarantees. If temporary Securities of any series are issued, the Company will cause definitive Securities of that series to be prepared without unreasonable delay. After the preparation of definitive Securities of such series, the temporary Securities of such series shall be exchangeable for definitive Securities of such series upon surrender of the temporary Securities of such series at the office or agency of the Company in a Place of Payment for that series, without charge to the Holder. Upon surrender for cancellation of any one or more temporary Securities of any series, the Company shall execute and the Trustee shall authenticate and deliver in exchange therefor one or more definitive Securities of the same series, of any authorized denominations and of like tenor and aggregate principal amount and, if applicable, having endorsed thereon the notations of Subsidiary Guarantees executed by the Subsidiary Guarantors. Until so exchanged, the temporary Securities of any series shall in all respects be entitled to the same benefits under this Indenture as definitive Securities of such series and tenor.
Temporary Securities Pending the preparation of definitive Securities of any series, the Company may execute, and upon Company Order the Trustee shall authenticate and deliver, temporary Securities which are printed, lithographed, typewritten, mimeographed or otherwise produced, in any authorized denomination, substantially of the tenor of the definitive Securities in lieu of which they are issued and with such appropriate insertions, omissions, substitutions and other variations as the officers executing such Securities may determine, as evidenced by their execution of such Securities. If temporary Securities of any series are issued, the Company will cause definitive Securities of that series to be prepared without unreasonable delay. After the preparation of definitive Securities of such series, the temporary Securities of such series shall be exchangeable for definitive Securities of such series upon surrender of the temporary Securities of such series at the office or agency of the Company in a Place of Payment for that series, without charge to the Holder. Upon surrender for cancellation of any one or more temporary Securities of any series, the Company shall execute and the Trustee shall authenticate and deliver in exchange therefor one or more definitive Securities of the same series, of any authorized denominations and of like tenor and aggregate principal amount. Until so exchanged, the temporary Securities of any series shall in all respects be entitled to the same benefits under this Indenture as definitive Securities of such series and tenor.
Temporary Suspension or Prohibition If the Employee is suspended and/or temporarily prohibited from participating in the conduct of the Bank's affairs by a notice served under Section 8(e)(3) or (g)(1) of the FDIA, 12 U.S.C. § 1818(e)(3) and (g)(1), the Bank's obligations under this Agreement shall be suspended as of the date of service, unless stayed by appropriate proceedings. If the charges in the notice are dismissed, the Bank may in its discretion (i) pay the Employee all or part of the compensation withheld while its obligations under this Agreement were suspended and (ii) reinstate in whole or in part any of its obligations which were suspended.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Ready for Occupancy For purposes of Section 1.3.2 of this Agreement, the Premises shall be deemed “Ready for Occupancy” upon the substantial completion of the Tenant Improvement Work. Subject to Section 4.2 below, the Tenant Improvement Work shall be deemed to be “substantially complete” upon the completion of the Tenant Improvement Work pursuant to the Approved Construction Drawings (as reasonably determined by Landlord), with the exception of any details of construction, mechanical adjustment or any other similar matter the non-completion of which does not materially interfere with Tenant’s use of the Premises.
Tenant’s Entry Into the Premises Prior to Substantial Completion Subject to the terms hereof and provided that Tenant and its agents do not interfere with, or delay, Contractor’s work in the Building and the Premises, at Landlord’s reasonable discretion, Contractor shall allow Tenant access to the Premises prior to the Substantial Completion of the Premises for the purpose of Tenant installing any necessary furniture, equipment or fixtures (including Tenant’s data and telephone equipment) in the Premises. Prior to Tenant’s entry into the Premises as permitted by the terms of this Section 6.01, Tenant shall submit a schedule to Landlord and Contractor, for their approval, which schedule shall detail the timing and purpose of Tenant’s entry, and Landlord will reasonably cooperate with Tenant to coordinate Landlord’s Contractor’s work of constructing the Tenant Improvements with such access by Tenant for the installation of Tenant’s furniture, equipment and fixtures. In connection with any such entry, Tenant acknowledges and agrees that Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees shall fully cooperate, work in harmony and not, in any manner, interfere with Landlord or Landlord’s Contractor, agents or representatives in performing work in the Building and the Premises, or interfere with the general operation of the Building and/or the Project; and such entry shall be subject to the site management rules of Landlord and Landlord’s Contractor. If at any time any such person representing Tenant shall not be cooperative or shall otherwise cause or threaten to cause any such disharmony or interference, including, without limitation, labor disharmony, and Tenant fails to immediately institute and maintain corrective actions as directed by Landlord, then Landlord may revoke Tenant’s entry rights upon twenty-four (24) hours’ prior written notice to Tenant. Tenant acknowledges and agrees that any such entry into and occupancy of the Premises or any portion thereof by Tenant or any person or entity working for or on behalf of Tenant shall be deemed to be subject to all of the terms, covenants, conditions and provisions of the Lease, excluding only the covenant to pay Rent (until the occurrence of the Lease Commencement Date). Tenant further acknowledges and agrees that Landlord shall not be liable for any injury, loss or damage which may occur to any of Tenant’s work made in or about the Premises in connection with such entry or to any property placed therein prior to the Lease Commencement Date, the same being at Tenant’s sole risk and liability. Tenant shall be liable to Landlord for any damage to any portion of the Premises, including the Tenant Improvement work, caused by Tenant or any of Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees. If the performance of Tenant’s work in connection with such entry causes extra costs to be incurred by Landlord or requires the use of any Building services, Tenant shall promptly reimburse Landlord for such extra costs and/or shall pay Landlord for such Building services at Landlord’s standard rates then in effect. In addition, Tenant shall hold Landlord harmless from and indemnify, protect and defend Landlord against any loss or damage to the Building or Premises and against injury to any persons caused by Tenant’s actions pursuant to this Section 6.01.
Common Areas - Changes Lessor shall have the right, in Lessor's sole discretion, from time to time:
Temporary Debentures Pending the preparation of definitive Debentures, the Company may execute and the Trustee shall authenticate and make available for delivery temporary Debentures that are typed, printed or lithographed. Temporary Debentures shall be issuable in any authorized denomination, and substantially in the form of the definitive Debentures in lieu of which they are issued but with such omissions, insertions and variations as may be appropriate for temporary Debentures, all as may be determined by the Company. Every such temporary Debenture shall be executed by the Company and be authenticated by the Trustee upon the same conditions and in substantially the same manner, and with the same effect, as the definitive Debentures. Without unreasonable delay the Company will execute and deliver to the Trustee or the Authenticating Agent definitive Debentures and thereupon any or all temporary Debentures may be surrendered in exchange therefor, at the principal corporate trust office of the Trustee or at any office or agency maintained by the Company for such purpose as provided in Section 3.2, and the Trustee or the Authenticating Agent shall authenticate and make available for delivery in exchange for such temporary Debentures a like aggregate principal amount of such definitive Debentures. Such exchange shall be made by the Company at its own expense and without any charge therefor except that in case of any such exchange involving a registration of transfer the Company may require payment of a sum sufficient to cover any tax, fee or other governmental charge that may be imposed in relation thereto. Until so exchanged, the temporary Debentures shall in all respects be entitled to the same benefits under this Indenture as definitive Debentures authenticated and delivered hereunder.
