Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded Vendor under this Agreement when the TIPS Member desires goods or services awarded to the Vendor. Notification may occur via phone, the web, courier, email, fax, or in person. Upon notification of a pending request, the awarded Vendor shall acknowledge the TIPS Member’s request as soon as possible, but must make contact with the TIPS Member within two working days. Status of TIPS Members as Related to This Agreement TIPS Members stand in the place of TIPS as related to this agreement and have the same access to the proposal information and all related documents. TIPS Members have all the same rights under the awarded Agreement as TIPS.
PRICE/DELIVERY Price(s) bid must be the price(s) for new goods, unless otherwise specified. Any bids containing modifying or “escalator” clauses will not be considered unless specifically requested in the bid specifications.
Delivery to Escrow Agent You may tender your escrow securities to a person or company in a business combination. At least five business days prior to the date the escrow securities must be tendered under the business combination, you must deliver to the Escrow Agent:
Shipping must be Freight On Board Destination to the delivery location designated on the Customer purchase order The Contractor will retain title and control of all goods until delivery is completed and the Customer has accepted the delivery. All risk of transportation and all related charges are the responsibility of the Contractor. The Customer will notify the Contractor and H-GAC promptly of any damaged goods and will assist the Contractor in arranging for inspection. The Contractor must file all claims for visible or concealed damage. Unless otherwise stated in the Agreement, deliveries must consist only of new and unused merchandise.
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
The OCN, From XXX, and Invoice Number will control the invoice sequencing The From XXX will be used to identify to <<customer_name>> which BellSouth XXX is sending the message. BellSouth and <<customer_name>> will use the invoice sequencing to control data exchange. BellSouth will be notified of sequence failures identified by <<customer_name>> and resend the data as appropriate. THE DATA WILL BE PACKED USING ATIS EMI RECORDS.
WARRANTY – DELIVERABLES The Contractor warrants and represents that all deliverables sold the City under the Contract shall be free from defects in design, workmanship or manufacture, and conform in all material respects to the specifications, drawings, and descriptions in the Solicitation, to any samples furnished by the Contractor, to the terms, covenants and conditions of the Contract, and to all applicable State, Federal or local laws, rules, and regulations, and industry codes and standards. Unless otherwise stated in the Solicitation, the deliverables shall be new or recycled merchandise, and not used or reconditioned.
How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000-000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent flooring inspector to verify the Warranty Holder’s warranty claims. The determination of the flooring inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/geowood-flooring-warranty/. Warranty Exclusions and Limitations: This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s GeoWood flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and (ii) maintained in accordance with Cali Bamboo’s GeoWood flooring care and maintenance guidelines found online at xxxxx://xxx.xxxxxxxxxx.xxx/floor-care-and-maintenance/ (the “Maintenance Guide”). Cali Bamboo will provide copies of these guides upon request by the Warranty Holder. This limited warranty only applies when the Flooring is used under normal traffic and other usage conditions. The limited warranty for Manufacturing Defects does not apply after the Warranty Holder has installed the Flooring, and product variation or error that does not exceed the 5% industry standard is not considered a Manufacturing Defect for purposes of this limited warranty. This limited warranty does not extend to or cover:
Service Delivery Grantee shall:
Non Delivery C15.1 Where the Goods, having been placed in transit, fail to be delivered to the Authority on the due date for delivery, the Authority shall, (provided that the Authority has been advised in writing of the dispatch of the Goods), within ten (10) Working Days of the notified date of delivery, give notice to the Contractor that the Goods have not been delivered and may request the Contractor free of charge to deliver substitute Goods within the timescales specified by the Authority or terminate the Contract in accordance with clause C13.4 (Delivery).
