Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.
Benchmark Unavailability Period Upon the Borrower’s receipt of notice of the commencement of a Benchmark Unavailability Period, the Borrower may revoke any pending request for a SOFR Borrowing of, conversion to or continuation of SOFR Loans to be made, converted or continued during any Benchmark Unavailability Period and, failing that, the Borrower will be deemed to have converted any such request into a request for a Borrowing of or conversion to Base Rate Loans. During a Benchmark Unavailability Period or at any time that a tenor for the then-current Benchmark is not an Available Tenor, the component of Base Rate based upon the then-current Benchmark or such tenor for such Benchmark, as applicable, will not be used in any determination of Base Rate.
Unavoidable Delay Except for the monetary obligations of Tenant under this Lease, neither party shall be chargeable with, liable for, or responsible to the other for anything or in any amount for any Unavoidable Delay and any Unavoidable Delay shall not be deemed a breach of or default in the performance of this Lease, it being specifically agreed that any time limit provision contained in this Lease (other than the scheduled expiration of the Term) shall be extended for the same period of time lost by Unavoidable Delay.
Landlord Delay Landlord’s (a) failure to comply with any time requirements expressly set forth in Paragraph 2.d. above with respect to Landlord’s obligation to provide notice of approval or disapproval of the Space Plan, Working Drawings or Change Orders, or (b) Landlord’s unreasonable interference with the completion of Tenant Improvements, including any failure or refusal of Landlord or Landlord’s agents or contractors to permit Tenant, its agents or contractors, access to and use of the Building or any Building facilities or services (including hoists, elevators, and loading docks) which access or use is reasonably required for the orderly and continuous performance of the work necessary to complete Tenant Improvements, are referred to collectively herein as “Landlord Delay” (provided that no Landlord Delay as described in clause (b) above will be deemed to have occurred unless and until Tenant has notified Landlord of the event which Tenant claims constitutes a Landlord Delay and Landlord has failed to cure such event within five (5) Business Days thereafter). Tenant will use commercially reasonable efforts to mitigate its damages and/or construction delays in the event of an alleged Landlord Delay. Notwithstanding anything to the contrary in this Paragraph 2, if and to the extent Tenant reasonably incurs a net increased cost (taking into account any cost saving Landlord might have facilitated by its actions, including any Landlord Delay) of design or construction of the Tenant Improvements as a direct result of any Landlord Delay (as reasonably evidenced by Tenant, with supporting documentation), Landlord will be responsible for such reasonable increased costs and Landlord’s Allowance will be increased by the amount of such reasonable increased cost. Further, when determining whether a particular Landlord Delay delayed Substantial Completion of the Tenant Improvements, the subject Landlord Delay shall be offset by any action or response by Landlord that achieved a reduction in Tenant’s construction schedule (each day saved in Tenant’s construction schedule being a “Schedule Saving Day”) and any aggregate Landlord Delay as described in this Paragraph 2.f. shall first be offset against, and reduced on a day-for-day basis by, the aggregate number of Schedule Saving Days. In the event of a disagreement between Landlord and Tenant as to whether a Landlord Delay has occurred and/or as to the application of this grammatical paragraph, either party may submit the issue to the dispute resolution procedure set forth in Paragraph 2.j. below. This Paragraph 2.f. is inapplicable to delays in Delivery, whether caused by Landlord, Landlord’s Contractor or otherwise (such delays being expressly covered by Paragraph 2.a. above) and this Paragraph 2.f. only applies to delays in the commencement or Substantial Completion of the Tenant Improvements following Delivery.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Force Majeur Except with respect to obligations to make payments hereunder, neither party shall be deemed in default hereunder, nor shall it hold the other party responsible for, any cessation, interruption or delay in the performance of its obligations hereunder due to causes beyond its reasonable control including, but not limited to: earthquake, flood, fire, storm or other natural disaster, act of God, labor controversy or threat thereof, civil disturbance or commotion, disruption of the public markets, war or armed conflict or the inability to obtain sufficient material, supplies, labor, transportation, power or other essential commodity or service required in the conduct of its business, including internet access, or any change in or the adoption of any law, ordinance, rule, regulation, order, judgment or decree.
Major Damage In the event of Major Damage to a Property prior to the Closing Date, then the applicable Seller shall have no obligation to repair such Major Damage and shall notify Purchaser in writing of such damage or destruction (the “Damage Notice”). Within ten (10) days after Purchaser’s receipt of the Damage Notice, Purchaser may elect at its option to give a Termination Notice for the damaged Property to Seller’s Representative. If Purchaser does not elect to terminate this Agreement with respect to the damaged Property, this transaction shall be closed in accordance with the terms of this Agreement either, at the election of the applicable Seller, (a) for the full Purchase Price for the damaged Property notwithstanding any such damage or destruction, and Purchaser shall, at Closing, execute and deliver an assignment and assumption (in a form reasonably required by the applicable Seller) of such Seller’ rights and obligations with respect to the insurance claim and related to such casualty, and thereafter Purchaser shall receive all remaining insurance proceeds pertaining to such claim (plus a credit against the applicable Purchase Price at Closing in the amount of any deductible payable by the applicable Seller in connection therewith and not spent by such Seller for demolition, site cleaning, restoration or other repairs); or (b) Purchaser shall receive a credit against the Base Purchase Price for the damaged Property for the full replacement costs of repair to the subject Property, plus, to the extent covered by such Seller’s insurance policy, any costs required pursuant to local code or zoning requirements, as determined by an independent third party reasonably acceptable to such Seller and Purchaser. In the event a Seller elects to assign such Seller's rights and obligations with respect to the insurance claim and related casualty to Purchaser as provided above, and if an AIMCO employee is the adjuster for the claim related thereto, Sellers covenant and agree that the adjuster shall act in accordance with standard insurance industry protocols in processing such claim (including, without limitation, the time taken to process such claim).
Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.
Excusable Delays Neither Party shall be held liable for any delay or failure in performance of any part of this Services Agreement by reason of any cause beyond its reasonable control, including, but not limited to, acts of God, acts of civil or military authority, government regulations, embargoes, epidemics, war, terrorist acts, riots, fires, explosions, earthquakes, nuclear accidents, floods, strikes, power blackouts affecting facilities, inability to secure products or services of other persons or transportation facilities, or acts or omissions of transportation common carriers, provided that the Party so affected shall use reasonable commercial efforts to remove such causes of non-performance. Upon the occurrence of any event of force majeure, the Party whose performance is prevented shall promptly give written notice to the other Party and the Parties shall promptly confer in good faith to agree upon reasonable action to minimize the impact of such event on the Parties.
