Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Submission of Grievance Information a) Upon appointment of the arbitrator, the appealing party shall within five days after notice of appointment forward to the arbitrator, with a copy to the School Board, the submission of the grievance which shall include the following:
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
Drug-Free Workplace Certification As required by Executive Order No. 90-5 dated April 12, 1990, issued by the Governor of Indiana, the Contractor hereby covenants and agrees to make a good faith effort to provide and maintain a drug-free workplace. The Contractor will give written notice to the State within ten (10) days after receiving actual notice that the Contractor, or an employee of the Contractor in the State of Indiana, has been convicted of a criminal drug violation occurring in the workplace. False certification or violation of this certification may result in sanctions including, but not limited to, suspension of contract payments, termination of this Contract and/or debarment of contracting opportunities with the State for up to three (3) years. In addition to the provisions of the above paragraph, if the total amount set forth in this Contract is in excess of $25,000.00, the Contractor certifies and agrees that it will provide a drug-free workplace by:
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
REQUIRED FOR PART 2 JOC - PRICING OF Regular Hours Coefficient What is your regular hours coefficient for the RS Means Price Book? (FAILURE TO RESPOND PROHIBITS PART 2 JOC EVALUATION) Remember that this is a ceiling price proposed. You can discount lower than your proposed contract coefficient, but not higher. This is one of three pricing questions that are required for consideration for award on this solicitation. Please consider your answer carefully. An explanation of the TIPS scoring of pricing is included in the attachments for your information. The below is an Example of how pricing model works (not intended to influence your proposed coefficient, you should propose a coefficient that you determine is right for your business): To propose the exact pricing as the RS Means Unit Price Book, you would insert a 1.0 and to propose a 5% discount for the RS Means Price Book would be a .95 regular hours coefficient and so on.
Written Evaluation The Superintendent in consultation with the Board shall review and assess the Administrator’s performance on or before February 1 of each year. The Administrator shall be formally evaluated in writing annually by the Superintendent on or before February 1 of each year. The evaluation shall include a description of the Administrator’s duties and responsibilities and the standards to which the Administrator is to perform. It shall consider the Administrator’s specific duties, responsibilities, management and competence as an Administrator; specify the Administrator’s strengths and weaknesses with supporting reasons; align with research based standards established by the Illinois State Board of Education and use data and indicators on student growth as a significant factor in rating performance. The evaluation shall also consist of a review of the Administrator’s progress toward meeting established professional, student performance and academic goals set forth in Appendix A and a review of the Administrator’s leadership and management performance relative to his current assignment. The written evaluation shall be signed by both the Superintendent and the Administrator. The Administrator may respond to the evaluation in writing and such response shall be attached to and included in the Administrator’s personnel file.
Documents Required to be Delivered on each Issuance Notice Date The Agent’s obligation to use its commercially reasonable efforts to place Shares hereunder shall additionally be conditioned upon the delivery to the Agent on or before the Issuance Notice Date of a certificate in form and substance reasonably satisfactory to the Agent, executed by the Chief Executive Officer, President or Chief Financial Officer of the Company, to the effect that all conditions to the delivery of such Issuance Notice shall have been satisfied as at the date of such certificate (which certificate shall not be required if the foregoing representations shall be set forth in the Issuance Notice).
Statement of Grievance The grievance shall contain a statement of:
