NOTICE OF ACCIDENTS 20.01 Tenant shall give notice to Landlord, promptly after Tenant learns thereof, of (i) any accident in or about the Demised Premises for which Landlord might be liable, (ii) all fires in the Demised Premises, (iii) all damages to or defects in the Demised Premises, including the fixtures, equipment and appurtenances thereof, for the repair of which Landlord might be responsible, and (iv) all damage to or defects in any parts or appurtenances of the Building’s sanitary, electrical, heating, ventilating, air-conditioning, elevator and other systems located in or passing through the Demised Premises or any part thereof.
Service Interruption Landlord shall not be liable in damages for any failure or interruption of any utility service to the Premises, except to the extent that any failure or interruption arises from the gross negligence or willful misconduct of Landlord. No failure or interruption of utility service for any reason shall entitle Tenant to terminate this Lease; provided, however, that if the failure or interruption of any Service to be repaired or maintained by Landlord and not the service provider continues for a period of forty-eight (48) hours or more, Tenant shall be entitled to an equitable abatement of Minimum Rent. Landlord shall not be obligated to provide any service or maintenance or to make any repairs pursuant to this Lease when such service, maintenance or repair is made necessary because of any wrongful act or misuse of any utility service by Tenant, Tenant's agents, employees, servants, contractors, subtenants or licensees. Landlord reserves the right to stop any Service when Landlord deems such stoppage necessary, whether by reason of accident or emergency, or for repairs or improvements or otherwise, provided, that any such period of stoppage shall be only so long as is reasonably required to effect any necessary repairs or maintenance. Landlord shall not be obligated to inspect the Premises and shall not be obligated to make any repairs or perform any maintenance hereunder unless first notified of the need thereof in writing or, in an emergency, verbally, followed by a written confirmation, by Tenant. Upon receipt of any such notice, Landlord shall commence any required repair work of an emergency nature as soon as possible and work as expeditiously as possible to complete such work. All other work of a non-emergency nature shall be performed as promptly as possible. If Landlord shall fail to commence emergency repairs or maintenance to be performed by Landlord and not the service provider within twenty-four (24) hours after said notice, or non-emergency repairs or maintenance within five (5) days after said notice, then Tenant shall be entitled to an equitable abatement of Minimum Rent for so long as such failure continues and an extension of the Lease Term for a period equal to the period of rent abatement.
Mail Service Interruption If by reason of any interruption of mail service, actual or threatened, any notice to be given to the Trustee would reasonably be unlikely to reach its destination by the time notice by mail is deemed to have been given pursuant to Section 14.3, such notice shall be valid and effective only if delivered at the appropriate address in accordance with Section 14.3.
Notice of Delay Within Fourteen (14) days after the date of occurrence of any cause of delay, on account of which the BUILDER claims that it is entitled under this Contract to a postponement of the Delivery Date, the BUILDER shall notify the BUYER in writing or by telefax confirmed in writing of the date when such cause of delay occurred. Likewise, within Fourteen (14) days after the date of ending of such cause of delay, the BUILDER shall notify the BUYER in writing or by xxxxxxx confirmed in writing of the date when such cause of delay ended. The BUILDER shall also notify the BUYER of the period, by which the Delivery Date is postponed by reason of such cause of delay, with all reasonable dispatch after it has been determined. If the BUILDER does not give the timely advice as above, the BUILDER shall lose the right to claim such delays as permissible delay. Failure of the BUYER to acknowledge to the BUILDER’s claim for postponement of the Delivery Date within Fourteen (14) days after receipt by the BUYER of such notice of claim shall be deemed to be a waiver by the BUYER of its right to object to such postponement of the Delivery Date.
Service Interruptions When necessary by reason of accident or emergency, or for repairs, alterations, replacements or improvements which in the reasonable judgment of Landlord are desirable or necessary to be made, or by reason of event(s) of Force Majeure, Landlord reserves the right to interrupt, curtail, stop or suspend (i) the furnishing of heating, elevator, air conditioning, and cleaning services and (ii) the operation of the plumbing and electric systems. Landlord shall exercise reasonable diligence to eliminate the cause of any such interruption, curtailment, stoppage or suspension, but there shall be no diminution or abatement of rent or other compensation due from Landlord to Tenant hereunder, nor shall this Lease be affected or any of the Tenant’s obligations hereunder reduced, and the Landlord shall have no responsibility or liability for any such interruption, curtailment, stoppage, or suspension of services or systems, except as provided herein. Landlord shall schedule all non-emergency interruptions, curtailments, stops or suspensions of services or systems in advance after consultation with Tenant, and shall make commercially reasonable efforts to avoid the same interfering with Tenant’s business. Notwithstanding the foregoing, Tenant shall be entitled to a proportionate abatement of Base Rent in the event of a Landlord Service Interruption (as defined below). For the purposes hereof, a “Landlord Service Interruption” shall occur in the event (i) the Premises shall lack any service which Landlord is required to provide hereunder thereby rendering at least fifty (50%) percent of the usable area of the Premises untenantable for the entirety of the Landlord Service Interruption Cure Period (as defined below), (ii) such lack of service was not caused by the act or omission of Tenant or any Tenant Party; (iii) Tenant in fact ceases to use at least fifty (50%) percent of the Premises for the entirety of the Landlord Service Interruption Cure Period; and (iii) such interruption of service was the result of causes, events or circumstances within the Landlord’s reasonable control and the cure of such interruption is within Landlord’s reasonable control. During such Landlord Service Interruption Period, Landlord will, if reasonably practical, cooperate with Tenant to arrange for the provision of any interrupted services on an interim basis via temporary measures until final corrective measures can be accomplished and Tenant will permit Landlord the necessary access to the Premises to remedy such lack of service, subject to the provisions of Section 9.06. For the purposes hereof, the “Landlord Service Interruption Cure Period” shall be defined as seven (7) consecutive Business Days after Landlord’s receipt of written notice from Tenant of the Landlord Service Interruption. This Section 6.03 shall be Tenant’s sole and exclusive remedy on account of an interruption of services or Landlord default resulting in an interruption of services other than Tenant’s right to obtain affirmative injunctive relief. This Section 6.03 shall not apply to any interruption or failure of services required to be provided by Landlord under Section 6.02(a) or Exhibit E attached hereto, which is caused in whole or in part by any act or omission of Tenant or any Tenant Party, or by any occurrence described in Section 16.09, or by any cause whatsoever other than those set forth in the first sentence of this Section 6.03. Notwithstanding the foregoing, if either Landlord or Tenant disputes in good faith whether, or the extent to which, an event is subject to the provisions of this Section 6.03, or the amount of Tenant’s abatement of Base Rent hereunder, such dispute shall be resolved in accordance with Section 16.17 of this Lease; provided, however, that in the event that it is ultimately determined that there was a Landlord Service Interruption, then Tenant shall have the right to a retroactive equitable abatement of Base Rent for the period as set forth above, provided that, if the Term expires before Tenant’s entire retroactive abatement has been effected, then Landlord shall immediately refund to Tenant any overpayment of Rent due under the Lease not yet received on account of the retroactive abatement.
Interruption Subject to Section 11, any failure to furnish, delay in furnishing, or diminution in the quality or quantity of any service resulting from any application of Law, failure of equipment, performance of maintenance, repairs, improvements or alterations, utility interruption, or event of Force Majeure (each, a “Service Interruption”) shall not render Landlord liable to Tenant, constitute a constructive eviction, or excuse Tenant from any obligation hereunder. Notwithstanding the foregoing, if all or a material portion of the Premises is made untenantable or inaccessible for more than three (3) consecutive business days after notice from Tenant to Landlord by a Service Interruption that (a) does not result from a Casualty (defined in Section 11), a Taking (defined in Section 13) or an Act of Tenant (defined in Section 10.1), and (b) can be corrected through Landlord’s reasonable efforts, then, as Tenant’s sole remedy, Monthly Rent shall xxxxx for the period beginning on the day immediately following such 3-business-day period and ending on the day such Service Interruption ends, but only in proportion to the percentage of the rentable square footage of the Premises made untenantable or inaccessible and not occupied by Tenant.
Notice of Subsequent Events If at any time during the ninety (90) day period after the Registration Statement becomes effective, any rumor, publication or event relating to or affecting the Company shall occur as a result of which in your opinion the market price of the Company Shares has been or is likely to be materially affected (regardless of whether such rumor, publication or event necessitates a supplement to or amendment of the Prospectus), the Company will, after written notice from you advising the Company to the effect set forth above, forthwith prepare, consult with you concerning the substance of and disseminate a press release or other public statement, reasonably satisfactory to you, responding to or commenting on such rumor, publication or event.
Notice of Force Majeure Each Party agrees to give the other Party prompt written notice of the occurrence of any Force Majeure Event, the nature thereof, and the extent to which the affected Party will be unable fully to perform its obligations hereunder. Each Party further agrees to use reasonable efforts to correct the Force Majeure Event as quickly as possible and to give the other Party prompt written notice when it is again fully able to perform such obligations.
Inability to Supply In the event that PerImmune is unable to supply [***] of Progenics' purchase orders for two consecutive quarters, then PerImmune agrees to provide Progenics the right and license to use the relevant Know-how to manufacture or have manufactured KLH for use in producing Ganglioside Vaccine, and to fully cooperate with regulatory authorities to qualify Progenics and/or its designee as a manufacturer of KLH. In such event, at Progenics' request, PerImmune shall promptly disclose to Progenics all Know-how and information reasonably necessary to manufacture KLH and the parties shall mutually agree upon a reasonable schedule for gradually reducing the amount of KLH purchased by Progenics from PerImmune, until such time PerImmune is able to reasonably demonstrate the ability to supply Progenics with its requirements.
Business Interruption Plan ALPS shall maintain in effect a business interruption plan, and enter into any agreements necessary with appropriate parties making reasonable provisions for emergency use of electronic data processing equipment customary in the industry. In the event of equipment failures, ALPS shall, at no additional expense to the Fund, take commercially reasonable steps to minimize service interruptions.
