Construction Cost 3.1. Construction Cost does not include the fees of the ARCHITECT/ENGINEER and consultants, the cost of the land, rights- of-way, or other costs, which is the responsibility of the State as provided in Paragraphs 2.2 through 2.3. or any of the contingencies available for the project unless specifically stated otherwise.
Indirect Cost Rates The System Agency may acknowledge an indirect cost rate for Grantees that is utilized for all applicable contracts. Grantee will provide the necessary financial documents to determine the indirect cost rate in accordance with the Uniform Grant Guidance (UGG) and Uniform Grant Management Standards (UGMS).
Direct Expenses 1. Fees and expenses of its directors (except the fees of those directors who are deemed to be "interested persons" of the Fund as that term is defined in the Investment Company Act of 1940) and the meetings thereof;
Construction Cost Budget The total cost to District of all elements of the Project designed or specified by the Architect, as adjusted during and at the end of the design phase in accordance with this Agreement and the Agreement for Architectural Services. The Construction Cost Budget does not include the compensation of the Project Design Team, the Program Manager (if any), the Construction Manager and any subconsultants, the cost of the land, rights-of-way, or financing which are the responsibility of the District.
Cost Estimates If this Agreement pertains to the design of a public works project, CONSULTANT shall submit estimates of probable construction costs at each phase of design submittal. If the total estimated construction cost at any submittal exceeds ten percent (10%) of CITY’s stated construction budget, CONSULTANT shall make recommendations to CITY for aligning the PROJECT design with the budget, incorporate CITY approved recommendations, and revise the design to meet the Project budget, at no additional cost to CITY.
Estimated Cost Estimated costs by construction phases for Specified Roads listed in A7 are stated by segments in the Schedule of Items. Such estimated costs are subject to adjustment under B3.3, B5.2, B5.21, B5.212, B5.25, and B5.26. Appropriately adjusted costs shall be made a part of a revised Schedule of Items and shown as adjustments to Timber Sale Account. The revised Schedule of Items shall supersede any prior Schedule of Items when it is dated and signed by Contracting Officer and a copy is furnished to Purchaser.
Project Cost a. The estimated cost of the Project is $ 97,740.00. This amount is based upon the Schedule of Financial Assistance in Exhibit "B", attached to and incorporated in this Agreement. Exhibit “B” may be modified by mutual execution of an amendment as provided for in paragraph 5.i.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.
Cost Estimate An estimate of the total project cost including but not limited to direct expenses, indirect expenses, land cost, and capital expenses.
Operating Expenses Unless modified in accordance with Exhibit D, Landlord maintenance addendum, attached hereto, it is the intention of the parties and they hereby agree that this shall be a triple net Lease, and the Landlord shall have no obligation to provide any services, perform any acts or pay any expenses, charges, obligations or costs of any kind whatsoever with respect to the Premises, and Tenant hereby agrees to pay one hundred percent (100%) of any and all Operating Expenses as hereafter defined for the entire term of the Lease and any extensions thereof in accordance with specific provisions hereinafter set forth. The term Operating expenses shall include all costs to Landlord of operating and maintaining the Building and related parking areas, and shall include, without limitation, real estate and personal property taxes and assessments, management fee, heating, electricity, water, waste disposal, sewage, operating materials and supplies, service agreements and charges, lawn care, snow removal, restriping, repairs, repaving, cleaning and custodial, security, insurance, the cost of contesting the validity or applicability of any governmental acts which may affect operating expenses, and all other direct operating costs of operating and maintaining the Building and related parking areas, unless expressly excluded from operating expenses. Notwithstanding the foregoing, operating costs (and Tenant's obligations in relation thereto) shall not include (i) any expense chargeable to a capital account or capital improvement, ground leases; principal or interest payments on any mortgage or deed of trust on the premises; (ii) any amount for which Landlord is reimbursed through insurance, by third persons, or directly by other tenants of the premises, (iii) repair costs occasioned by fire, windstorm or other casualty, (iv) any construction, repair or maintenance expenses or obligations that are the sole responsibility of Landlord (not to be reimbursed by Tenant), (v) leasing commissions and other expenses incurred in connection with leasing any other area located on the premises to any other party, (vi) any expense representing an amount paid to an affiliate or subsidiary of Landlord which is in excess of the amount which would be paid in the absence of such relationship, and (vii) costs of items and services for which Tenant reimburses Landlord or pays third persons directly.
