Is there an Extension of Time. The Board may permit a claim to be filed after the six month period expires if, in the opinion of the Board, it is just to do so.
Is there an Extension of Time Sample Clauses
Related to Is there an Extension of Time
No Extension of Time If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures set forth herein.
Extension of Time If the Executive shall be in violation of any provision of this Article 6, then each time limitation set forth in this Article 6 shall be extended for a period of time equal to the period of time during which such violation or violations occur. If the Company seeks injunctive relief from such violation in any court, then the covenants set forth in this Article 6 shall be extended for a period of time equal to the pendency of such proceeding including all appeals by the Executive.
Delays and Extension of Time If the Contractor is delayed at any time in the progress of providing goods and/or services by an act or neglect of the District, or by changes ordered in the work, or by labor disputes, strikes, insurrections, fire, acts of God; unusual but well documented and excusable delays in performance, or other causes beyond the Contractor’s control, or by delay authorized by the District, then the contract Term of service may be extended by a contract amendment for such reasonable time as the District and the Contractor may agree.
Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:
Amendments; Renewal Any amendments, consents to or waivers of the terms of this Contract must be in writing and signed by both parties. The parties may renew this Contract by their signed, written instrument.
Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.
Extension of Agreement Prior to the original expiration date of this Agreement, the Parties mutually agree to extend this Agreement to the February 15 extension date identified in Paragraph VIII(A). The Parties acknowledge that no further extensions of this Agreement are authorized. Xxxxxxxxx has hereunto signed on this Day of , 20 . Landowner(s): The Secretary of the Department of Agriculture, acting and through his or her authorized representative has executed this Contract on behalf of the United States of America on this Day of , 20 . THE UNITED STATES OF AMERICA BY: NONDISCRIMINATION STATEMENT The U.S. Department of Agriculture (USDA) prohibits discrimination in all its programs and activities on the basis of race, color, national origin, age, disability, and where applicable, sex, marital status, familial status, parental status, religion, sexual orientation, genetic information, political beliefs, reprisal, or because all or a part of an individual’s income is derived from any public assistance program. (Not all prohibited bases apply to all programs.) Persons with disabilities who require alternative means for communication of program information (Braille, large print, audiotape, etc.) should contact USDA’s TARGET Center at 0 (000) 000-0000 (voice and TDD). To file a complaint of discrimination, write to USDA, Director, Office of Civil Rights, 0000 Xxxxxxxxxxxx Xxxxxx, XX., Xxxxxxxxxx, XX 00000-0000 or call (000) 000-0000 (voice) or (000) 000-0000 (TDD). USDA is an equal opportunity provider and employer. PRIVACY ACT STATEMENT
DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.
EXPIRATION DATE AND EXTENSION This Contract expires January 31, 2023, unless it is terminated sooner pursuant to Article XX of the General Terms and Conditions, which are incorporated into this Contract by reference. This Contract may be extended up to three additional one-year periods upon request of Sourcewell and with written agreement by the Contractor, not to exceed a total of four years.
Calculation of Time For the purposes of this Agreement, “days” refers to calendar days unless otherwise specified.
