Final Design Package Sample Clauses

Final Design Package a. At a minimum, this package must include final plans, specifications, engineer’s opinion of cost which includes a schedule of eligible costs, and project construction schedule.
Sample 1
AutoNDA by SimpleDocs
Final Design Package. Before proceeding with soil improvement, or as approved by the PURCHASER, the SOIL CONTRACTOR shall submit a complete and final soil improvement design package based on the conceptual design, Exhibit of the subcontract, this specification, and the results of any additional investigation and pre-production test program(s). The package must contain documents and drawings that describe the geometry, configuration, and design properties of the proposed soil modification. The package must show that the design meets the design criteria of Section 4.1, must include the calculations as described in Section 4.2 through 4.6, and must include proposed acceptance criteria as detailed in Section 4.7 through 4.10.
Sample 1
Final Design Package. Xxxx 0000 – Final Design Plans Consultant will advance the 90% design to final completion, and incorporate agreed upon City review comments into the final design. Consultant will incorporated DSD review comments. Final Design Plans will be signed and stamped by a professional civil engineer registered in the state of California. Task 6020 – Final Specifications and Calculations Consultant will advance the 90% specifications to final completion and incorporate agreed upon City review comments. Consultant will prepare final Calculations. Xxxx 0000 – Opinion of Probable Construction Cost Subconsultant KEH will prepare an opinion of probable construction cost at the 90% design, and update it at the final completion stage. Any opinion of probable construction cost prepared by the Consultant represents its judgments as a design professional and is supplied for the general guidance of the City. Since the Consultant has no control over the cost of labor and material, or over competitive bidding or market conditions, Consultant does not guarantee the accuracy of such opinions as compared to contractor bids or actual cost to the City. Task 6040 – Final QA/QC This task accounts for review activities for the final design package. It includes internal QA/QC review, responses to City 90% Design review comments. Consultant will prepare internal QA/QC review, incorporate QA/QC comments. Respond to City review comments. Deliverables, Format, and Standards: Deliverables – AECOM will provide comply with and provide the following:
Sample 1
Final Design Package. Xxxx 0000 – Final Design Plans Consultant will advance the 90% design to final completion, and incorporate agreed upon City review comments into the final design. Final Design Plans will be signed and stamped by a professional civil engineer registered in the state of California. Task 6020 – Final Specifications and Calculations Consultant will advance the 90% specifications to final completion and incorporate agreed upon City review comments. Consultant will modify final Calculations, only as needed to address design changes. Task 6030 – Opinion of Probable Construction Cost Subconsultant KEH will prepare an opinion of probable construction cost at the 90% design, and update it at the final completion stage. Any opinion of probable construction cost prepared by the Consultant represents its judgments as a design professional and is supplied for the general guidance of the City. Since the Consultant has no control over the cost of labor and material, or over competitive bidding or market conditions, Consultant does not guarantee the accuracy of such opinions as compared to contractor bids or actual cost to the City. Task 6040 – Final QA/QC This task accounts for review activities for the 90% design package, both internal and external reviews. It includes internal QA/QC review, responses to City review comments, and attendance at the City Review Comment Consultation meeting by PM. Consultant will prepare internal QA/QC review, incorporate QA/QC comments. Respond to all City review comments. Consultant will attend a meeting with City staff to discuss and resolve all comments after the City has completed its review. Submittals and Reviews Documents, drawings, specifications, and electronic information prepared by Consultant for this project are not intended or represented to be suitable for reuse by the City or other parties on other projects, or extensions of this project. Consultant will not be liable for any such use of completed or uncompleted documents without specific authorization. Electronic data delivered to the City will not include the professional stamp or signature of an engineer or architect. Consultant will not be liable for claims or losses arising out of deterioration of electronic files due to inappropriate storage, lengthy storage, or software obsolescence. Deliverables, Format, and Standards: Deliverables – AECOM will provide comply with and provide the following:
Sample 1
Final Design Package. Upon receipt of the Pre-Final Design Package review comments, the Design/Builder shall update the design package and provide a Final, stamped Design Package ready to be incorporated into a new interim agreement or issued as a solicitation. The Design/Builder shall certify that the complete system will function together for its intended purpose in accordance with the Owner’s requirements. The Design/Builder accepts the responsibility to modify previously approved work if it is necessary to provide a complete and properly functioning D&C SCADA system without additional compensation unless authorized by the Owner.
Sample 1
Final Design Package. B. Predecessors:
Sample 1

Related to Final Design Package

  • Punch List If, at any time after the Project has been Physically Completed, there shall exist any item or items requiring completion or correction, then the Developer agrees to use all reasonable diligence to complete or correct such item or items so that each conforms to the Final Plans. The parties shall make a Punch-List of the items requiring completion or correction (the "Punch List"). Each item on the Punch-List shall be assigned a reasonable value based upon the reasonable cost of completion or correction of the same or such other value as may be required by the Owner's lender ("Punch-List Amount"). The Developer shall give its written undertaking to complete each such item within forty-five (45) days (or such other period of time as is mutually agreed upon by the parties).

  • APPROVAL OF PLANS AND SPECIFICATIONS The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.

  • Final Space Plan Tenant shall supply Landlord with four (4) copies signed by Tenant of its final space plan for the Premises before any architectural working drawings or engineering drawings have been commenced. The final space plan (the “Final Space Plan”) shall include a layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein. Landlord may request clarification or more specific drawings for special use items not included in the Final Space Plan. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Space Plan for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly (i) cause the Final Space Plan to be revised to correct any deficiencies or other matters Landlord may reasonably require, and (ii) deliver such revised Final Space Plan to Landlord.

  • Acceptance; Rejection A holder of Notes may accept the offer to prepay made pursuant to this Section 8.3 by causing a notice of such acceptance to be delivered to the Company not later than 15 days after receipt by such holder of the most recent offer of prepayment. A failure by a holder of Notes to respond to an offer to prepay made pursuant to this Section 8.3 shall be deemed to constitute a rejection of such offer by such holder.

  • Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).

  • Space Plans Prior to drafting any Construction Drawings, Tenant shall furnish Landlord with Tenant's final space plans for the Premises ("Space Plans"). The Space Plans shall show locations of all proposed improvements, including partitions, cabinetry, equipment and fixtures, shall identify materials and finishes by location, and shall specify the location of any proposed structural floor penetrations, the location and extent of floor loading in excess of Building capacity, if any, any special HVAC requirements, the location and description of any special plumbing requirements, and any special electrical requirements. In addition, the Space Plans shall show telephone and telecommunications facilities, and computer and electronic data facilities. Landlord shall approve or disapprove the Space Plans by written notice given to Tenant within ten (10) business days after receipt of the Space Plans. Landlord shall not unreasonably withhold its approval of the Space Plans, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plans if, in Landlord's good faith judgment, any one or more of the following situations exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Buildings; or (b) the proposed Tenant Improvements may impair the structural strength of the Buildings, adversely affect any Building Systems or materially adversely affect the value of the Buildings; or (c) the specifications for the proposed Tenant Improvements are not consistent with, or would detract from, the character or image of the Project. If Landlord disapproves the Space Plans, Landlord shall return the Space Plans to Tenant with a statement of Landlord's reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plans by written notice given to Tenant within five (5) business days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plans.

  • Final Working Drawings After the Final Space Plan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, Title 24 calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is sufficiently complete to allow all of Tenant’s Agents to bid on the work and to obtain all applicable permits (collectively, the ‘‘Final Working Drawings”) and shall submit the same to Landlord for Landlord’s approval, which shall not be unreasonably withheld, conditioned, or delayed. Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings, Landlord shall not unreasonably withhold, condition, or delay its approval of the Final Working Drawings. Landlord shall approve or reasonably EXHIBIT A disapprove of the Final Working Drawings within ten (10) business days after Landlord’s receipt thereof. If Landlord reasonably withholds its approval, Landlord shall provide Tenant with the specific reasons therefor.

  • Punchlist Upon completion of the Performance Tests and prior to Substantial Completion of a Subproject, Owner and Contractor shall inspect the Subproject, and Contractor shall prepare a proposed Punchlist of items identified as needing to be completed or corrected as a result of such inspection. Contractor shall promptly provide the proposed Punchlist to Owner for its review, together with an estimate of the time and cost necessary to complete or correct each Punchlist item. Contractor shall add to the proposed Punchlist any Punchlist items that are identified by Owner within ten (10) Days after Owner’s receipt of the proposed Punchlist from Contractor, and Contractor shall immediately initiate measures to complete or correct, as appropriate, any item on Contractor’s proposed Punchlist (including those items identified by Owner during Owner’s review) that are not of a Punchlist nature. Notwithstanding anything to the contrary in this Agreement, Contractor and Owner are not required as a condition of Substantial Completion of a Subproject to agree upon and identify every Punchlist item and include it on the Punchlist, but Contractor is required to complete as a condition of Substantial Completion of such Subproject that does not meet the definition of Punchlist as provided in Section 1.1. In the event of a dispute regarding whether a specific item of Work meets the definition of Punchlist under Section 1.1, the Parties shall resolve such dispute in accordance with Section 18.1A. Owner shall provide Contractor with access to the Work after Substantial Completion of a Subproject sufficient to enable Contractor to complete all Punchlist items, so long as such access does not unreasonably interfere with operation of a Subproject after Substantial Completion of the Subproject or the Existing Facility and subject to any reasonable security or safety requirements of Owner. Upon Contractor’s completion or correction of any items necessary to achieve Substantial Completion of a Subproject, as modified by any Owner additions, such Punchlist shall govern Contractor’s performance of the Punchlist items up to Final Completion. All Work on the Punchlist shall be completed by the date required for Final Completion, as specified in Section 5.3C, or Owner may, in addition to any other rights that it may have under this Agreement, complete such Punchlist Work at the expense of Contractor. In the event Owner elects to complete such Punchlist Work, Contractor shall pay Owner, within ten (10) Days after receipt of written notice from Owner, all reasonable costs and expenses incurred by Owner in performing such Punchlist Work, or, at Owner’s sole discretion, Owner may withhold or offset amounts owed to Contractor or collect on the Letter of Credit in accordance with Section 7.8 in the amount of such costs and expenses. Any Defective Work identified after agreement between the Parties of the Punchlist shall be corrected by Contractor as a Warranty item under Article 12.

  • Permits; Certificate of Occupancy Lender shall have received a copy of all Permits necessary for the use and operation of the Property and the certificate(s) of occupancy, if required, for the Property, all of which shall be in form and substance reasonably satisfactory to Lender.

  • Title Examination Within thirty (30) days after Purchaser’s exercise of the Option, Purchaser shall have the right to obtain, at Purchaser’s expense, a current survey of the Property (the “Updated Survey”) and an ALTA Title Commitment for the Property from a title company acceptable to Purchaser (the “Title Company”), setting forth the status of title to the Property, and showing all liens, claims, encumbrances, reservations, restrictions and other matters, if any, relating to the Property (the “Title Commitment”), including legible copies of all encumbrances, restrictive covenants and other documents evidencing exceptions to said Title Commitment (the “Exception Documents”). If the Title Commitment and/or Updated Survey reveals any exception(s) to title to which Purchaser objects (a “Title Objection”) and is(are) not either (i) listed as title exceptions in the title insurance policy and/or survey obtained by Seller in connection with the closing of the Mezzanine Loan and/or (ii) permitted by this Agreement (collectively, the “Permitted Encumbrances”), Purchaser may notify Seller in writing that it would like Seller to cure or remove such Title Objections. Seller shall have the right, but not the obligation (except as set forth below), to remedy or cure any such Title Objection(s) during the twenty (20) day period following Seller’s receipt thereof (the “Cure Period”). Purchaser shall have the continuing right to have such title examination and Title Commitments updated from time to time, and to obtain updates to the Survey, and to give Seller written notice of any Title Objections appearing of record, or otherwise created, after the effective date of the initial Title Commitment and being revealed by any title examination, Survey or investigation of the Property, and Purchaser shall be entitled to object (in the same manner as set forth hereinabove) to matters shown by the updated Title Commitments or updated Survey or investigations. Seller shall have the right, but not the obligation (except as set forth below), to remedy those Title Objections identified by Purchaser to the satisfaction of Purchaser within twenty (20) days after Purchaser’s notice. If any of the Title Objections are not so cured or remedied, or provision satisfactory to Purchaser made therefor, prior to any closing date selected by Purchaser, then Purchaser, at its election, shall have the right and option to either: (a) accept title to the Property subject to said uncured Title Objections that Purchaser elects to accept, and any Title Objection accepted by Purchaser in writing shall become part of the Permitted Encumbrances; or (b) terminate this Agreement by written notice to Seller, in which event, immediately upon receipt of said notice, this Agreement shall terminate, be null and void and of no further force or effect. Notwithstanding the foregoing, Seller, at Seller’s sole cost and expense, shall be obligated to cure or remove at or before Closing all mortgages, deeds of trust, deeds to secure debt, judgments liens, mechanics and materialman’s liens, and other monetary liens against the Property, whether or not Purchaser objects thereto, and Purchaser shall credit the cost to cure, satisfy, release and remove such matters against the Purchase Price provided the same is actually paid by Purchaser or Title Company on Seller’s behalf. In addition, Seller shall not allow any easements, liens, leases, licenses, permits or other encumbrances to be placed on or granted with respect to the Property, nor shall Seller convey any rights in the Property, without the prior written consent of Purchaser, except to the extent expressly permitted, or consented to in writing by Purchaser under the Mezzanine Loan Documents. If any such prohibited easements, liens, leases, licenses, permits or other encumbrances arise after the Effective Date, notwithstanding any other term or provision of this Agreement to the contrary, Seller shall, at its sole cost and expense, cure, satisfy, release and remove such matters prior to Closing; provided, however, that any easements or encumbrances that are taken by eminent domain shall be governed by the terms of Section 5 immediately below.

Time is Money Join Law Insider Premium to draft better contracts faster.