Executed Change Directive/Contract Modification/Change Order Required Sample Clauses

Executed Change Directive/Contract Modification/Change Order Required. Only a written Change Directive, Contract Modification or change order, executed by the Department’s contracting officer as indicted in Exhibit H, may make changes to the Agreement. In particular, but without limitation, a written Change Directive or Change Order executed by the Department’s Contracting Officer is the only means by which changes may be made to the Substantial or Final Completion Dates, the Preconstruction Fee, the Construction Management Fee, or the Guaranteed Maximum Price.
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs

Related to Executed Change Directive/Contract Modification/Change Order Required

  • Change Order (5) The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.

  • For Lump Sum Change Order The payment and extension of time (if any) provided by this Change Order constitutes compensation in full to the Contractor and its Subcontractors and Suppliers for all costs and markups directly and indirectly attributable to the Change Order herein, for all delays related thereto and for performance of changes within the time stated.

  • Construction Change Directive A written order prepared and issued by the District, the Construction Manager, and/or the Architect and signed by the District and the Architect, directing a change in the Work.

  • Construction Change Directives 7.3.1 A Construction Change Directive is written order prepared by the Architect and signed by the Owner and Architect, directing a change in the Work and stating a proposed basis for adjustment, if any, in the Contract Sum, or Contract Time, or both. The Owner may by Construction Change Directive, without invalidating the Contract, order changes in the Work within the general scope of the Contract consisting of additions, deletions or other revisions, the Contract Sum and Contract Time being adjusting accordingly.

  • Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).

  • CONTRACTOR’S SUBMISSION OF CONTRACT MODIFICATIONS In connection with any Contract modification, OGS reserves the right to:  request additional information  reject Contract modifications  remove Products from Contract modification requests  request additional discounts for new or existing Products

  • Contract Modification The conditions of this timber sale are completely set forth in this contract. Except as provided in B8.32 and B8.33, this contract can be modified only by written agreement between the parties. Only Contracting Officer may make contract modifications, with compensating adjustments to Current Contract Rates where appropriate, on behalf of Forest Service.

  • Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Housing.

  • Change Orders and Contract Amendments 33.1 The Procuring Entity may at any time order the Supplier through notice in accordance GCC Clause 8, to make changes within the general scope of the Contract in any one or more of the following:

  • OGS Centralized Contract Modifications OGS, an Authorized User, or the Contractor may suggest modifications to the Centralized Contract or its Appendices. Except as specifically provided herein, modifications to the terms and conditions set forth herein may only be made with mutual written agreement of the Parties. Modifications may take the form of an update or an amendment. “

Time is Money Join Law Insider Premium to draft better contracts faster.